Emergencies 10.3.1 In any emergency affecting the safety of persons or property, the Contractor shall act to prevent threatened damage, injury or loss. Any additional compensation or extension of time claimed by the Contractor on account of emergency work shall be determined as provided in Article 12 for Changes in the Work.
Emergency A circumstance requiring immediate action; a sudden, unexpected happening; an unforeseen occurrence or condition.
Emergency Generator Although Landlord is the owner of emergency generator and related automatic transfer switches serving the Building and the 901 Building (collectively, the “Emergency Generator”), prior to the date of this First Amendment, Tenant, as the sole tenant of the Building and the 901 Building, has been operating and maintaining the Emergency Generator. Tenant shall, on the date that is 1 day after the mutual execution and delivery of this First Amendment by the parties (“EG Transfer Date”), (x) deliver the Emergency Generator to Landlord in good working order with a full tank of diesel (y) assign to, transfer and deliver to Landlord all governmental permits and licenses (to the extent such permits and licenses are assignable), if any, warranties (to the extent assignable), operating and maintenance manuals, records and other documents concerning the Emergency Generator, and (y) terminate any service, maintenance or other contracts maintained by Tenant with respect to the Emergency Generator. Tenant has not been obligated to maintain a wastewater permit in connection with the Emergency Generator. With respect to any permit required for the Emergency Generator, Landlord acknowledges and agrees that Tenant has been in the process of obtaining a generator permit in connection with a Tenant permitting process underway with the Bay Area Air Quality Management District (“BAAQMD”) for the 901 Building, that Tenant will remove the generator from its permit application with BAAQMD, and that Landlord will need to obtain a generator permit from BAAQMD in its own name. To the best of Tenant’s knowledge, Tenant does not have any other permits in connection with the Emergency Generator. To the extent Tenant has current contracts with any vendors for the Emergency Generator, Tenant and Landlord shall reasonably cooperate to assign or terminate such contracts in the manner set forth in Section 14 above regarding utilities. To the extent it is not possible for Tenant to remove the request for a generator permit from its BAAQMD application or to assign or terminate any service maintenance or other contracts within 1 day after the mutual execution and delivery of this First Amendment, Tenant shall not be in default hereunder if Tenant promptly commences efforts to do so and diligently performs until such actions have been completed within a reasonable period after such date. Landlord shall, within 5 days of the EG Transfer Date, as part of Expenses, conduct such testing of the Emergency Generator required, in Landlord’s sole and absolute discretion, to determine whether the Emergency Generator is, in fact, in good working order. If such testing discloses that the Emergency Generator is not in good working order, Landlord shall have the right, at Tenant’s sole cost and expense, to perform any maintenance and/or repairs required to put the Emergency Generator in good working order. Following the EG Transfer Date, Landlord’s sole obligation for either providing emergency generators or providing emergency back-up power to Tenant shall be: (i) to provide emergency generators with not less than the current capacity of the Emergency Generator and Tenant shall be entitled to Tenant’s share of the capacity thereof available for use by all tenants of the Building and the 901 Building, collectively, in accordance with the rentable area of the Premises and the 901 Building and the collective rentable areas of the Building and the 901 Building occupied by such other tenants, (ii) to contract with a third party to maintain the emergency generators (“Emergency Generator Servicer”) as per the manufacturer’s standard maintenance guidelines, and (iii) to obtain and maintain licenses for the emergency generators as required by applicable law. Landlord shall have no obligation to provide Tenant with operational emergency generators or back-up power or to supervise, oversee or confirm that the Emergency Generator Servicer or any other third party maintaining the emergency generators is maintaining the generators as per the manufacturer’s standard guidelines or otherwise. Landlord shall provide to Tenant copies of any reports received by Landlord from the Emergency Generator Servicer regarding its maintenance and repairs of the emergency generators; provided, however, that in no event shall Landlord’s failure to deliver such reports constitute a default by Landlord under the Lease. During any period of replacement, repair or maintenance of the emergency generators when the emergency generators are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up generator or generators or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generators will be operational at all times or that emergency power will be available to the Premises when needed. Landlord shall provide Tenant with not less than five (5) business days’ notice of the scheduled disruption in the operation of the emergency generators. In the case of an emergency, Landlord shall provide Tenant with notice of any emergency disruption as soon as reasonably possible after Landlord becomes aware of the need for such emergency disruption.
Landlord’s Contribution Landlord shall, in the manner hereinafter set forth, contribute the lesser of (i) the actual cost of Tenant’s Work or (ii) $1,698,800.00 (calculated on the basis of $40.00 per rentable square foot of the Relocation Premises) (“Landlord’s Contribution”) towards the costs of designing and constructing Tenant’s Work. Tenant shall be entitled to use up to $424,700.00 (i.e., $10.00 per rentable square foot of the Relocation Premises) of Landlord’s Contribution towards the cost of architectural and engineering drawings, furniture, fixtures and equipment, permitting costs, cabling, wiring and moving costs, signage, third-party legal fees and consulting costs incurred by Tenant in the performance of Tenant’s Work. Provided no Default of Tenant exists at the time that Tenant submits any Requisition (as hereinafter defined) on account of Landlord’s Contribution, Landlord shall pay the cost of the work shown on each Requisition submitted by Tenant to Landlord within twenty-five (25) days of Landlord’s receipt thereof. For the purposes hereof, a “Requisition” shall mean written documentation showing in reasonable detail the costs of the Tenant’s Work then installed by Tenant in the Premises. Each Requisition shall be accompanied by evidence reasonably satisfactory to Landlord that all work covered by previous Requisitions has been fully paid. Landlord shall have the right, upon reasonable advance notice to Tenant, to inspect Tenant’s books and records relating to each Requisition in order to verify the amount thereof. Tenant shall submit Requisition(s) no more often than monthly. Landlord’s Contribution, less a 10% retainage (which retainage shall be payable as part of the final draw), shall be paid to the general contractor that performs Tenant’s Work, in periodic disbursements within twenty-five (25) days after receipt of the following documentation: (i) an application for payment and sworn statement of contractor substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein; (ii) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment found in AIA Document G702, Application and Certificate of Payment; (iii) Contractor’s, subcontractor’s and material supplier’s waivers of liens which shall cover all Tenant’s Work for which disbursement is being requested and all other statements and forms required for compliance with the mechanics’ lien laws of the state in which the Relocation Premises is located, together with all such invoices, contracts, or other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing Tenant’s Work; (v) plans and specifications for Tenant’s Work, together with a certificate from an AIA architect that such plans and specifications comply in all material respects with all laws affecting the Building, Property and Relocation Premises; (vi) copies of all construction contracts for Tenant’s Work, together with copies of all change orders, if any; and (vii) a request to disburse from Tenant containing an approval by Tenant of the work done and a good faith estimate of the cost to complete Tenant’s Work. Upon completion of Tenant’s Work, and prior to final disbursement of Landlord’s Contribution, Tenant shall furnish Landlord with: (I) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Tenant’s Work, and (5) the certification of Tenant’s architect that Tenant’s Work has been installed in a good and workmanlike manner in accordance with the Tenant’s Plans, and in accordance with applicable laws, codes and ordinances. In no event shall Landlord be required to disburse Landlord’s Contribution more than one (1) time per month. Notwithstanding anything herein to the contrary, Landlord shall not be obligated to disburse any portion of Landlord’s Contribution during the continuance of an uncured Default by Tenant under the Lease, and Landlord’s obligation to disburse shall only resume when and if such Default is cured. If Tenant does not submit a request for payment of the entire Landlord’s Contribution to Landlord in accordance with the provisions contained in this Section II (D) on or before the date that is twelve (12) months after the Relocation Date, any unused amount shall accrue to the sole benefit of Landlord, it being understood that Tenant shall not be entitled to any credit, abatement or other concession in connection therewith. Tenant shall be responsible for all applicable state sales or use taxes, if any, payable in connection with Tenant’s Work and Landlord’s Contribution.
Repairs Tenant shall, at Tenant’s own expense, keep the Premises, including all improvements, fixtures, furnishings, and systems and equipment to the extent located therein (including plumbing fixtures and equipment such as dishwashers, garbage disposals, refrigerators, coffee makers and Insta Hot and similar dispensers), and the portion of the floor or floors of the Building on which the Premises are located, in good order, repair and condition at all times during the Lease Term. In addition, Tenant shall, at Tenant’s own expense, but under the supervision and subject to the prior approval of Landlord, and within any reasonable period of time specified by Landlord, promptly and adequately repair all damage to the Premises and replace or repair all damaged, broken, or worn fixtures and appurtenances, except for damage caused by ordinary wear and tear or beyond the reasonable control of Tenant; provided however, that, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a fifteen percent (15%) supervisory fee forthwith upon being billed therefor. Notwithstanding the foregoing, Landlord shall be responsible for repairs to the exterior walls, foundation and roof of the Building, the structural portions of the floors of the Building, and the base building systems and equipment of the Building, except to the extent that such repairs are required due to the negligence or willful misconduct of Tenant; provided, however, that if such repairs are due to the negligence or willful misconduct of Tenant, Landlord shall nevertheless make such repairs at Tenant’s expense, or, if covered by Landlord’s insurance, Tenant shall only be obligated to pay any deductible in connection therewith. Landlord may, but shall not be required to, enter the Premises at all reasonable times to make such repairs, alterations, improvements or additions to the Premises or to the Project or to any equipment located in the Project as Landlord shall desire or deem necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree. Tenant hereby waives any and all rights under and benefits of subsection 1 of Section 1932 and Sections 1941 and 1942 of the California Civil Code or under any similar law, statute, or ordinance now or hereafter in effect.
Emergency Repairs a) The landlord must post and maintain in a conspicuous place on the residential property, or give to the tenant in writing, the name and telephone number of the designated contact person for emergency repairs.
Service Interruptions The Company may need to interrupt Your access to the Website to perform maintenance or emergency services on a scheduled or unscheduled basis. You agree that Your access to the Website may be affected by unanticipated or unscheduled downtime, for any reason, but that the Company shall have no liability for any damage or loss caused as a result of such downtime.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Tenant’s Repairs Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
