of ITB. The Bidders shall provide financial turnover of the firm for the last three years duly certified by statutory auditors.
of ITB. Not satisfying any of the qualification criteria will render the bid non-responsive and financial bids of such bidders will not be opened.
of ITB. In case a bidder fails to meet the above mentioned qualification criteria, their bids shall be treated as non- responsive and financial bids of such bidders shall not be opened.
of ITB. The Bidder shall indicate the value of the order executed by him together with the details of name of the party, order value, scope of work / component breakup, completion period stipulated in the order and actual completion period. The completion certificate, awarded by the client on its letter head should have a mention of start date, date of completion and value of the work executed by the Bidder. In case the work was performed by the Bidder in a JV, the same shall be supported by a Client Certificate enumerating the claimant share also. In case the work was performed by the bidder as a sub-contractor, the bidder shall submit similar completion certificate awarded to it by the main contractor and countersigned by the Employer / Client of the main contractor.
of ITB. The Bidder shall indicate the value of the order executed by him together with the details of name of the party, order value, scope of work / component breakup, completion period stipulated in the order and actual completion period. The completion certificate, awarded by the client on its letter head should have a mention of start date, date of completion and value of the work executed by the Bidder. The Bidder can provide the details of the works that have been substantially completed. “Substantially Completed Works” shall be based on completion of 80% or more works that have been financially completed under the claimed relevant component of the contract. Substantial completion of works shall be supported by client certificates with the name of the work including component breakup of relevant work to the extent of similar work, work order value, start date, percentage of similar work completed till date of issue of the Tender in financial terms (Net Payment received against the Contract) as indicated in Form 4B. In case the work was performed by the Bidder in a JV, the same shall be supported by a Client Certificate enumerating the claimant share also. In case the work was performed by the bidder as a sub-contractor, the bidder shall submit similar completion certificate awarded to it by the main contractor and countersigned by the Employer / Client of the main contractor.
of ITB. The Bidders shall submit Form 4J, Section IV in support of this criteria.
of ITB. 17.3 The text of the questions raised and the responses that may become necessary as a result of the Pre-Bid Meeting, will be prepared in the form of Addendum / Corrigendum /Clarification to the Tender Document and will be uploaded on websites of GAIL, Govt. and GAIL’s e-Portal (in case of e-tendering) and not through the minutes of the Pre-Bid Meeting.
of ITB. 6.9.11 In case of JV, for availing the benefits of MSME all the participating JV members must be registered under MSME acts and relevant provisions.
of ITB. 6.2. The proceeds of the Performance Guarantee shall be payable to the Procuring Agency as compensation for any loss resulting from the Service Provider’s failure to complete its obligations under the Contract. 6.3. As per Rule-56 of PPR-14, the performance guarantee shall be denominated in the currency of the Contract acceptable to the Procuring Agency and shall be in one of the following forms: (a) a bank guarantee or an irrevocable letter of credit issued by a reputable bank located in the Procuring Agency’s country, in the form provided in the Bidding documents or another form acceptable to the Procuring Agency; or (b) a cashier’s or certified cheque or CDR. 6.4. The performance guarantee will be discharged by the Procuring Agency and returned to the Service Provider not later than thirty (30) days following the date of completion of the Service Provider’s performance obligations under the Contract, including any warranty obligations, unless specified otherwise in SCC.
