Common use of Number of days for submission of Project Plans Clause in Contracts

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A) Environmental Management Plan: Site Management Plan: Commissioning and Handover Plan: Work Health and Safety Plan: ESD and WOL Plan: Other: [SPECIFY] Number of days for review of Project Plans: (Clause 9.2(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect or completion of a Variation to overcome a Defect: (Clause 9.11) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ PAYMENT Times for submission of payment claims by the Contractor to the Contract Administrator: (Clause 12.2(a)) Monthly on the ………….................... day of each month Number of business days for payment: (Clause 12.5) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate: (Clause 12.13) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators Australia, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. any other State or Territory, the Chair of the Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) CLAUSE 15 ‑ DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b), 6.7(d)(iii)B, 8.19(e), 8.29, 9.5, 9.9(b)(i), 9.10, 10.4, 10.5(d)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii), 11.3(c)(i)B, 11.3(c)(ii)B, 11.3(c)(iii)B, 12.4, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e). Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Institute of Arbitrators and Mediators Australia unless otherwise stated)

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Local Industry Capability Plan: 14 days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: Commissioning and Handover Plan: days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Local Industry Capability Plan: 14 days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days CLAUSE 9 - TIME Additional causes of a Defect or completion delay entitling the Contractor to claim an extension of a Variation to overcome a Defecttime: (Clause 9.119.4(a)(i)) Maintenance required 1. Unless a direction is given under clause 8.4(a)(ii) and the Contractor is responsible for the non-conformance, a Variation; 2. Proceedings being taken by adjacent or neighbouring owners or occupiers; 3. Statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Contractor or any subcontractor of the Contractor; 4. Inclement weather at the Site excluding the conditions resulting from Contractor during Defects Liability Periodinclement weather; 5. Delay of any governmental authority in giving any Approval for the Works; 6. Paragraphs (c), (d) or (e) of the Commonwealth Risks; 7. A change in respect of a Statutory Requirement after the Award Date; 8. A Latent Condition; 9. Valuable, archaeological or special interest items found on or in the Site; 10. If clause 1 of the Special Conditions applies, Latent Hazardous Substances, Asbestos, ACM or GHS Material; 11. A Pandemic Adjustment Event; and 12 A bushfire, a flood, an earthquake or a cyclone which directly impacts the carrying out of the Contractor’s Activities Delay Damages: (Clause 9.149.6) PlannedWhere there are no Stages, the daily cap on the extra costs reasonably incurred for the Works is: Unplanned$ [To be inserted following selection of the successful Tenderer] per working day If there are Stages, the daily cap on the extra costs reasonably incurred for each Stage is: Defects Liability Period Review and Report (additional): (Clause 9.15) Stage Maximum delay damages $ [To be inserted following selection of the successful Tenderer] per working day $ [To be inserted following selection of the successful Tenderer] per working day $ [To be inserted following selection of the successful Tenderer] per working day $ [To be inserted following selection of the successful Tenderer] per working day CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor to the Contract Administrator: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month month. Email address for copy of tax invoice: (Clause 11.5(a)) xxxxxxxx@xxxxxxx.xxx.xx Number of business days for payment: (Clause 12.511.5(b)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators Australia, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. any other State or Territory, the Chair of the Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) CLAUSE 15 ‑ DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b), 6.7(d)(iii)B, 8.19(e), 8.29, 9.5, 9.9(b)(i), 9.10, 10.4, 10.5(d)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii), 11.3(c)(i)B, 11.3(c)(ii)B, 11.3(c)(iii)B, 12.4, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e). Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Institute of Arbitrators and Mediators Australia unless otherwise stated).

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A6.14(a)(ii)A) Environmental Management Plan: Plan [INSERT (IF APPLICABLE)] Site Management Plan: Commissioning and Handover Plan: Plan [INSERT (IF APPLICABLE)] Work Health and Safety Plan: ESD and WOL Plan: Plan [INSERT (IF APPLICABLE)] Other: [SPECIFY] [INSERT (IF APPLICABLE)] Number of days for review of Project Plans: (Clause 9.2(a)(ii)B6.14(a)(ii)B) Period by which Defects Liability Period will be extended following rectification Environmental Management Plan [INSERT (IF APPLICABLE)] Site Management Plan [INSERT (IF APPLICABLE)] Work Health and Safety Plan [INSERT (IF APPLICABLE)] Other: [SPECIFY] [INSERT (IF APPLICABLE)] Manual of a Defect or completion Fire Protection Engineering and Building Code of a Variation to overcome a DefectAustralia Certification: (Clause 9.116.15) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) 6.17 [DOES/DOES NOT] apply CLAUSE 10 ‑ 8 - TIME Maximum intervals between program updates by ContractorConsultant: (Clause 10.2(b8.2(b)) [INSERT A TIME PERIOD FOR PROGRAM UPDATES, e.g. Monthly] Program format to be compatible withsoftware: (Clause 10.2(e8.2(d)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] INSERT THE TYPE OF PROGRAM TO BE USED, ENSURING SPECIFICATION OF APPROVED EQUIVALENTS, e.g. Microsoft Project or approved equivalent equivalent] CLAUSE 12 ‑ 10 - PAYMENT (OPTION 1) Payment (Option 1): (Clause 10) Clause 10 [DOES/DOES NOT] apply Times for submission of payment claims by the Contractor to the Contract AdministratorConsultant: (Clause 12.2(a10.2(a)) [IF CLAUSE 10 APPLIES SELECT APPLICABLE TIME FOR SUBMISSION OF PAYMENT CLAIMS AND DELETE REFERENCE TO TIME THAT IS NOT APPLICABLE] [MONTHLY] Monthly on the ………….................... [INSERT DAY e.g. 28th] day of each month Number [OR , IF THE SITE IS NOT IN NSW] [ON COMPLETION OF MILESTONES] Upon Completion of business days for paymentMilestones in accordance with the Milestone Fee Payment Schedule set out in the Fee Schedule. [IF CLAUSE 10 DOES NOT APPLY INSERT, Not Applicable] Payment of Workers and Subconsultants: (Clause 12.510.12) To the extent that the relevant part of the Contractor's Activities is carried out in: 1[IF CLAUSE 10 APPLIES, SELECT APPLICABLE OPTION. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate: (Clause 12.13) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) OPTION 1 APPLIES IF THE SERVICES ARE BEING PERFORMED IN NEW SOUTH WALES] [OPTION 1/ OPTION 2] applies. (Option 1 2 applies unless otherwise stated) [IF CLAUSE 10 DOES NOT APPLY INSERT, Not applicable] Appointed Adjudicator/Prescribed AppointerAppointed/Authorised Nominating Authority: (Clause 12.20(d10.14(d)) [IF CLAUSE 10 APPLIES, INSERT To the extent that the relevant part of the Contractor's Activities Services is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators AustraliaResolution Institute, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. Victoria, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 3. any other State or TerritoryTerritory (save for Queensland), the Chair of the Resolution Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting OR IF CLAUSE 10 DOES NOT APPLY INSERT, Not Applicable] Accounting records (additional): (Clause 12.22(b10.15) [IF CLAUSE 10 APPLIES INSERT DETAILS FOR ADDITIONAL ACCOUNTING RECORDS (IF ANY); OR IF CLAUSE 10 DOES NOT APPLY INSERT, Not Applicable] Estate Information (Clause 10.16) [IF CLAUSE 10 APPLIES SELECT APPLICABLE OPTION] Clause 10.16 [DOES/DOES NOT] apply. (Clause 10.16 applies unless otherwise stated) [IF CLAUSE 10 DOES NOT APPLY INSERT, Not Applicable] CLAUSE 10A - PAYMENT (OPTION 2) Payment (Option 2): (Clause 10A) Clause 10A [DOES/DOES NOT] apply Times for submission of payment claims by the Consultant: (Clause 10A.2(a)) ................................................................................................... [IF CLAUSE 14 ‑ 10A APPLIES select applicable TIME FOR SUBMISSION OF PAYMENT CLAIMS AND DELETE REFERENCE TO TIME THAT IS NOT applicable] [MONTHLY] Monthly on the [INSERT DAY e.g. 28th] day of each month [OR, IF THE SITE IS NOT IN NSW] [ON COMPLETION OF MILESTONES] Upon Completion of Milestones in accordance with the Milestone Fee Payment Schedule set out in the Fee Schedule. [IF CLAUSE 10A does not APPLY INSERT, Not Applicable] Number of days for payment: (Clause 10A.4) [IF CLAUSE 10A APPLIES INSERT NUMBER OF DAYS FOR PAYMENT] [INSERT] days (30 days unless otherwise specified) [IF CLAUSE 10A DOES NOT APPLY INSERT, Not applicable] Accounting records (additional): (Clause 10A.10) [IF CLAUSE 10A APPLIES INSERT DETAILS FOR ADDITIONAL ACCOUNTING RECORDS (IF ANY); OR IF CLAUSE 10A DOES NOT APPLY INSERT, Not Applicable] Estate Information (Clause 10A.11) [IF CLAUSE 10A APPLIES SELECT APPLICABLE OPTION] Clause 10A.11 [DOES/DOES NOT] apply. (Clause 10A.11applies unless otherwise stated) [IF CLAUSE 10A DOES NOT APPLY INSERT, Not Applicable] CLAUSE 11 - TERMINATION Number of days to remedy breach: (Clauses 14.3(cClause 11.3(c) and 14.4(b11.4(b)) CLAUSE 15 ‑ DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b), 6.7(d)(iii)B, 8.19(e), 8.29, 9.5, 9.9(b)(i), 9.10, 10.4, 10.5(d)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii), 11.3(c)(i)B, 11.3(c)(ii)B, 11.3(c)(iii)B, 12.4, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e). Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Institute of Arbitrators and Mediators Australia unless otherwise stated)[INSERT] days

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Pandemic Management Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: Commissioning and Handover Plan: days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect or completion of a Variation to overcome a DefectEnvironmental Management Plan: (Clause 9.11) Maintenance required from Contractor during Defects Liability Perioddays ESD and WOL Plan: (Clause 9.14) Planneddays Estate Information Provision Plan: Unplanneddays Pandemic Management Plan: Defects Liability Period Review days Project Lifecycle and Report (additional): (Clause 9.15) HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days CLAUSE 10 ‑ 9 - TIME Maximum intervals between program updates by ContractorSubcontractor: (Clause 10.2(b9.2(b)(ii)) Program format to be compatible with: (Clause 10.2(e9.2(b)(iv)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent Additional causes of delay entitling the Contractor to claim and extension of time: (Clause 9.4(a)(i)) 1. Unless a direction is given under clause 8.4(a)(ii) and the Contractor is responsible for the non-conformance, a Variation; 2. Proceedings being taken by adjacent or neighbouring owners or occupiers; 3. Statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Contractor or any subcontractor of the Contractor; 4. Inclement weather at the Site excluding the conditions resulting from inclement weather; 5. Delay of any governmental authority in giving any Approval for the Subcontract Works; 6. Paragraphs (c), (d) or (e) of the Contractor Risks; 7. A change or variance in respect of a Statutory Requirement after the Award Date; 8. A Latent Condition; 9. Valuable, archaeological or special interest items found on or in the Site; 10. If clause 1 of the Special Conditions applies, Latent Hazardous Substances, Asbestos, ACM or GHS Material; 11. A Pandemic Adjustment Event; and 12. A bushfire, a flood, an earthquake or a cyclone which directly impacts the carrying out of the Subcontractor’s Activities. Delay Damages: (Clause 9.6) Clause 9.6 [DOES/DOES NOT] apply. (Clause 9.6 applies unless otherwise stated) If clause 9.6 applies: Where there are no Stages, the daily cap on the extra costs reasonably incurred for the Subcontract Works is: $ per working day If there are Stages, the daily cap on the extra costs reasonably incurred for each Stage is: Stage Maximum delay damages $ per working day $ per working day $ per working day CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor Subcontractor to the Contract AdministratorContractor's Representative: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month Percentage of Retention Moneys: (Clause 11.5(a)) (unless otherwise stated the following retention percentages apply: the Contractor may deduct 10% from each payment until 5% of the Subcontract Price is retained as retention moneys) Email address for copy of tax invoice (Clause 11.5(b)) xxxxxxxx@xxxxxxx.xxx.xx Number of business days for payment: (Clause 12.511.5(c)) To the extent that the relevant part of the ContractorSubcontractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the MCC Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators Australia, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. any other State or Territory, the Chair of the Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) CLAUSE 15 ‑ DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b), 6.7(d)(iii)B, 8.19(e), 8.29, 9.5, 9.9(b)(i), 9.10, 10.4, 10.5(d)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii), 11.3(c)(i)B, 11.3(c)(ii)B, 11.3(c)(iii)B, 12.4, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e). Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Institute of Arbitrators and Mediators Australia unless otherwise stated).

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Management Local Industry Capability Plan: Site Management Plan: Commissioning and Handover Plan: 14 days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] [EG. Project Lifecycle and HOTO Plan, Environmental Management Plan, ESD and WOL Plan, Quality Plan or Site Management Plan and any additional Project Plans] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect Local Industry Capability Plan: 14 days Work Health and Safety Plan: days Other: [SPECIFY] [EG. Project Lifecycle and HOTO Plan, Environmental Management Plan, ESD and WOL Plan, Quality Plan or completion of a Variation to overcome a DefectSite Management Plan and any additional Project Plans] days CLAUSE 9 - TIME Agreed Damages: (Clause 9.119.6) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) $ for each day for which an extension of time is granted due to a breach of contract by the Commonwealth CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor to the Contract AdministratorPDS Contractor: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month month. Number of business days for payment: (Clause 12.511.5(b)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract AdministratorPDS Contractor; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.1611.14) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority/Adjudication Registry: (Clause 12.20(d11.16(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators AustraliaResolution Institute, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. Victoria, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 3. any other State or Territory, the Chair of the Resolution Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b11.18(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number Limits of days to remedy breachaccuracy for quantities in Schedule of Rates : (Clauses 14.3(cClause 11.20) and 14.4(b)Upper Limit: (115% unless otherwise stated) Lower Limit: (85% unless otherwise stated) CLAUSE 13 - COMPLETION Liquidated Damages: (Clause 13.5) For the Works is $ per day For each Section is: Section Liquidated Damages $ per day $ per day $ per day $ per day Incentive: (Clause 13.6) Clause 13.6 [DOES/DOES NOT] apply. (Clause 13.6 does not apply unless otherwise stated) Date: Amount: CLAUSE 15 ‑ - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b1.3(b), 6.7(d)(iii)B, 8.19(e6.5(a), 8.296.5(d), 6.9(d)(ii), 7.3(f)(ii) and (g), 8.3, 8.4(d)(ii) and the second last paragraph of clause 8.4, 8.5(e) and the second last paragraph of clause 8.5, 9.5, 9.9(b)(i9.7(b), 9.10, 10.4, 10.5(d)(i10.3(b)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii10.3(b)(ii), 11.3(c)(i)B11.4, 11.3(c)(ii)B13.1, 11.3(c)(iii)B17.4(e)(ii) and (iii). If clause 1 of the Special Conditions applies, 12.4clause 1.1(d) and 1.1(g) of the Special Conditions. If clause 7 of the Special Conditions applies, 13.2(b)(ii)clause 7.1(b)(i) of the Special Conditions. If clause 20 of the Special Conditions applies, 14.8(a), 18.4(b), 19.3(e)clause 20.2(b)(iv) and the second last paragraph of (b) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute of Arbitrators and Mediators Australia unless otherwise statedspecified)

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Local Industry Capability Plan: 14 days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: Commissioning and Handover Plan: days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Local Industry Capability Plan: 14 days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] days CLAUSE 9 - TIME Additional causes of a Defect or completion delay entitling the Contractor to claim an extension of a Variation to overcome a Defecttime: (Clause 9.119.4(a)(i)) Maintenance required 1. Unless a direction is given under clause 8.4(a)(ii) and the Contractor is responsible for the non-conformance, a Variation; 2. Proceedings being taken by adjacent or neighbouring owners or occupiers; 3. Statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Contractor or any subcontractor of the Contractor; 4. Inclement weather at the Site excluding the conditions resulting from Contractor during Defects Liability Periodinclement weather; 5. Delay of any governmental authority in giving any Approval for the Works; 6. Paragraphs (c), (d) or (e) of the Commonwealth Risks; 7. A change in respect of a Statutory Requirement after the Award Date; 8. A Latent Condition; 9. Valuable, archaeological or special interest items found on or in the Site; 10. If clause 1 of the Special Conditions applies, Latent Hazardous Substances, Asbestos, ACM or GHS Material; and 11. A Pandemic Relief Event. Delay Damages: (Clause 9.149.6) PlannedWhere there are no Stages, the daily cap on the extra costs reasonably incurred for the Works is: Unplanned$ [To be inserted following selection of the successful Tenderer] per working day If there are Stages, the daily cap on the extra costs reasonably incurred for each Stage is: Defects Liability Period Review and Report (additional): (Clause 9.15) Stage Maximum delay damages $ [To be inserted following selection of the successful Tenderer] per working day $ [To be inserted following selection of the successful Tenderer] per working day $ [To be inserted following selection of the successful Tenderer] per working day $ [To be inserted following selection of the successful Tenderer] per working day CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor to the Contract Administrator: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month month. Email address for copy of tax invoice: (Clause 11.5(a)) xxxxxxxx@xxxxxxx.xxx.xx Number of business days for payment: (Clause 12.511.5(b)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators Australia, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. any other State or Territory, the Chair of the Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) CLAUSE 15 ‑ DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b), 6.7(d)(iii)B, 8.19(e), 8.29, 9.5, 9.9(b)(i), 9.10, 10.4, 10.5(d)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii), 11.3(c)(i)B, 11.3(c)(ii)B, 11.3(c)(iii)B, 12.4, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e). Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Institute of Arbitrators and Mediators Australia unless otherwise stated).

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Local Industry Capability Plan: 14 days Pandemic Management Plan: Site Management Plan: Commissioning and Handover Plan: days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] [EG. Project Lifecycle and HOTO Plan, Environmental Management Plan, ESD and WOL Plan, Estate Information Provision Plan, Quality Plan or Site Management Plan and any additional Project Plans] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect Local Industry Capability Plan: 14 days Pandemic Management Plan: days Work Health and Safety Plan: days Other: [SPECIFY] [EG. Project Lifecycle and HOTO Plan, Environmental Management Plan, ESD and WOL Plan, Estate Information Provision Plan, Quality Plan or completion of a Variation to overcome a DefectSite Management Plan and any additional Project Plans] days CLAUSE 9 - TIME Agreed Damages: (Clause 9.119.6) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) $ for each day for which an extension of time is granted due to a breach of contract by the Commonwealth CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor to the Contract AdministratorPDS Contractor: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month month. Email address for copy of tax invoice: (Clause 11.5(a)) xxxxxxxx@xxxxxxx.xxx.xx Number of business days for payment: (Clause 12.511.5(b)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract AdministratorPDS Contractor; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.1611.14) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d11.16(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators AustraliaResolution Institute, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. Xxxxxxxx, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 3. any other State or TerritoryTerritory (save for Queensland), the Chair of the Resolution Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b11.18(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number Limits of days to remedy breachaccuracy for quantities in Schedule of Rates : (Clause 11.20) Upper Limit: (115% unless otherwise stated) Lower Limit: (85% unless otherwise stated) Reporting Entity: (Clauses 14.3(c11.21 to 11.26) and 14.4(b)[To be inserted following selection of the successful Tenderer - noting that clauses 11.21 to 11.26 will only apply where the successful Tenderer is a Reporting Entity for the purposes of the Payment Times Procurement Connected Policy] Clauses 11.21 to 11.26 [DO/DO NOT] apply. CLAUSE 13 - COMPLETION Liquidated Damages: (Clause 13.5) For the Works is $ per day For each Section is: Section Liquidated Damages $ per day $ per day $ per day $ per day Incentive: (Clause 13.6) Clause 13.6 [DOES/DOES NOT] apply. (Clause 13.6 does not apply unless otherwise stated) Date: Amount: CLAUSE 15 ‑ - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b1.3(b), 6.7(d)(iii)B, 8.19(e6.5(a), 8.296.5(d), 6.8(d)(ii), 7.3(f)(ii) and (g), 7.7, 8.3, 8.4(d)(ii) and the second last paragraph of clause 8.4, 8.5(e) and the second last paragraph of clause 8.5, 9.5, 9.9(b)(i9.7(b), 9.10, 10.4, 10.5(d)(i10.3(b)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii10.3(b)(ii), 11.3(c)(i)B11.4, 11.3(c)(ii)B13.1, 11.3(c)(iii)B17.4(e)(ii) and (iii). If clause 1 of the Special Conditions applies, 12.4clause 1.1(d) and 1.1(g) of the Special Conditions. If clause 7 of the Special Conditions applies, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e)clause 7(b)(i) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute of Arbitrators and Mediators Australia unless otherwise statedspecified)

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Management Local Industry Capability Plan: Site Management Plan: Commissioning and Handover Plan: 14 days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] [EG. Project Lifecycle and HOTO Plan, Environmental Management Plan, ESD and WOL Plan, Estate Information Provision Plan, Quality Plan or Site Management Plan and any additional Project Plans] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect Local Industry Capability Plan: 14 days Work Health and Safety Plan: days Other: [SPECIFY] [EG. Project Lifecycle and HOTO Plan, Environmental Management Plan, ESD and WOL Plan, Estate Information Provision Plan, Quality Plan or completion of a Variation to overcome a DefectSite Management Plan and any additional Project Plans] days CLAUSE 9 - TIME Agreed Damages: (Clause 9.119.6) Maintenance required from Contractor during Defects Liability Period: (Clause 9.14) Planned: Unplanned: Defects Liability Period Review and Report (additional): (Clause 9.15) $ for each day for which an extension of time is granted due to a breach of contract by the Commonwealth CLAUSE 10 ‑ TIME Maximum intervals between program updates by Contractor: (Clause 10.2(b)) Program format to be compatible with: (Clause 10.2(e)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor to the Contract AdministratorPDS Contractor: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month month. Email address for copy of tax invoice: (Clause 11.5(a)) xxxxxxxx@xxxxxxx.xxx.xx Number of business days for payment: (Clause 12.511.5(b)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the Contract AdministratorPDS Contractor; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.1611.14) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d11.16(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators AustraliaResolution Institute, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. Xxxxxxxx, any one of the following: (a) Resolution Institute, Victorian Chapter; (b) Building Adjudication Victoria Inc; or (c) Rialto Adjudications Pty Ltd; or 3. any other State or TerritoryTerritory (save for Queensland), the Chair of the Resolution Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b11.18(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number Limits of days to remedy breachaccuracy for quantities in Schedule of Rates : (Clauses 14.3(cClause 11.20) and 14.4(b)Upper Limit: (115% unless otherwise stated) Lower Limit: (85% unless otherwise stated) CLAUSE 13 - COMPLETION Liquidated Damages: (Clause 13.5) For the Works is $ per day For each Section is: Section Liquidated Damages $ per day $ per day $ per day $ per day Incentive: (Clause 13.6) Clause 13.6 [DOES/DOES NOT] apply. (Clause 13.6 does not apply unless otherwise stated) Date: Amount: CLAUSE 15 ‑ - DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b1.3(b), 6.7(d)(iii)B, 8.19(e6.5(a), 8.296.5(d), 6.8(d)(ii), 7.3(f)(ii) and (g), 8.3, 8.4(d)(ii) and the second last paragraph of clause 8.4, 8.5(e) and the second last paragraph of clause 8.5, 9.5, 9.9(b)(i9.7(b), 9.10, 10.4, 10.5(d)(i10.3(b)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii10.3(b)(ii), 11.3(c)(i)B11.4, 11.3(c)(ii)B13.1, 11.3(c)(iii)B17.4(e)(ii) and (iii). If clause (a) of the Special Conditions applies, 12.4clause a.1(d) and a.1(g) of the Special Conditions. If clause (g) of the Special Conditions applies, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e)clause g.1(b)(i) of the Special Conditions. Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Resolution Institute of Arbitrators and Mediators Australia unless otherwise statedspecified)

Number of days for submission of Project Plans. (Clause 9.2(a)(ii)A8.7(a)(ii)A) Environmental Management Plan: days ESD and WOL Plan: days Estate Information Provision Plan: days Project Lifecycle and HOTO Plan: days Quality Plan: days Site Management Plan: Commissioning and Handover Plan: days Work Health and Safety Plan: ESD and WOL Plan: days Other: [SPECIFY] days Number of days for review of Project Plans: (Clause 9.2(a)(ii)B8.7(a)(ii)B) Period by which Defects Liability Period will be extended following rectification of a Defect or completion of a Variation to overcome a DefectEnvironmental Management Plan: (Clause 9.11) Maintenance required from Contractor during Defects Liability Perioddays ESD and WOL Plan: (Clause 9.14) Planneddays Estate Information Provision Plan: Unplanneddays Project Lifecycle and HOTO Plan: Defects Liability Period Review days Quality Plan: days Site Management Plan: days Work Health and Report (additional): (Clause 9.15) Safety Plan: days Other: [SPECIFY] days CLAUSE 10 ‑ 9 - TIME Maximum intervals between program updates by ContractorSubcontractor: (Clause 10.2(b9.2(b)(ii)) Program format to be compatible with: (Clause 10.2(e9.2(b)(iv)) [PRIMAVERA SURETRAK/MICROSOFT PROJECT] or approved equivalent Additional causes of delay entitling the Contractor to claim and extension of time: (Clause 9.4(a)(i)) 1. Unless a direction is given under clause 8.4(a)(ii) and the Contractor is responsible for the non-conformance, a Variation; 2. Proceedings being taken by adjacent or neighbouring owners or occupiers; 3. Statewide industrial disputation or other industrial disputation caused by the Commonwealth, which in neither case is caused or contributed to by the Contractor or any subcontractor of the Contractor; 4. Inclement weather at the Site excluding the conditions resulting from inclement weather; 5. Delay of any governmental authority in giving any Approval for the Subcontract Works; 6. Paragraphs (c), (d) or (e) of the Contractor Risks; 7. A change or variance in respect of a Statutory Requirement after the Award Date; 8. A Latent Condition; 9. Valuable, archaeological or special interest items found on or in the Site; 10. If clause 1 of the Special Conditions applies, Latent Hazardous Substances, Asbestos, ACM or GHS Material; and 11. A Pandemic Relief Event. Delay Damages: (Clause 9.6) Clause 9.6 [DOES/DOES NOT] apply. (Clause 9.6 applies unless otherwise stated) If clause 9.6 applies: Where there are no Stages, the daily cap on the extra costs reasonably incurred for the Subcontract Works is: $ per working day If there are Stages, the daily cap on the extra costs reasonably incurred for each Stage is: Stage Maximum delay damages $ per working day $ per working day $ per working day CLAUSE 12 ‑ 11 - PAYMENT Times for submission of payment claims by the Contractor Subcontractor to the Contract AdministratorContractor's Representative: (Clause 12.2(a11.2(a)) Monthly on the ………….................... day of each month Percentage of Retention Moneys: (Clause 11.5(a)) (unless otherwise stated the following retention percentages apply: the Contractor may deduct 10% from each payment until 5% of the Subcontract Price is retained as retention moneys) Email address for copy of tax invoice (Clause 11.5(b)) xxxxxxxx@xxxxxxx.xxx.xx Number of business days for payment: (Clause 12.511.5(c)) To the extent that the relevant part of the ContractorSubcontractor's Activities is carried out in: 1. Queensland or New South Wales: 5; or 2. any other State or Territory: 10 Interest rate10. Interest: (Clause 12.1311.11) 1. In the case of damages - the Australian Taxation Office-sourced General Interest Charge Rate current at the due date for payment or such other rate nominated in writing from time to time by the MCC Contract Administrator; or 2. In the case of late payments - the greater of: (a) the rate in paragraph (1); and (b) the rate of interest prescribed under any applicable Security of Payment Legislation. Option for payment of workers and subcontractors: (Clause 12.16) [OPTION 1/ OPTION 2] applies. (Option 1 applies unless otherwise stated) Appointed Adjudicator/Prescribed Appointer/Authorised Nominating Authority: (Clause 12.20(d)) To the extent that the relevant part of the Contractor's Activities is carried out in: 1. the Northern Territory or Western Australia: (a) the appointed adjudicator is …………............................; or (b) if no appointed adjudicator is appointed, the prescribed appointer is the Chair of the Institute of Arbitrators and Mediators Australia, Northern Territory Chapter or Western Australian Chapter (as the case may be); or 2. any other State or Territory, the Chair of the Institute of Arbitrators and Mediators Australia of the Chapter in that State or Territory. Facilities and infrastructure accounting (additional): (Clause 12.22(b)) ................................................................................................... CLAUSE 14 ‑ TERMINATION Number of days to remedy breach: (Clauses 14.3(c) and 14.4(b)) CLAUSE 15 ‑ DISPUTES Directions to be subject of an expert determination if disputed: (Clause 15.2) Directions under clauses: 4.2(b), 6.7(d)(iii)B, 8.19(e), 8.29, 9.5, 9.9(b)(i), 9.10, 10.4, 10.5(d)(i), 11.3(a)(i)B, 11.3(a)(i)C, 11.3(a)(ii)B 11.3(a)(ii)C, 11.3(a)(iii)B, 11.3(a)(iii)C, 11.3(b)(ii), 11.3(c)(i)B, 11.3(c)(ii)B, 11.3(c)(iii)B, 12.4, 13.2(b)(ii), 14.8(a), 18.4(b), 19.3(e). Industry expert who will conduct expert determinations: (Clause 15.3(a)(i)) Nominating authority for industry expert: (Clause 15.3(a)(ii)) (The President for the time being of the Institute of Arbitrators and Mediators Australia unless otherwise stated).