Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.
Architect 4.1.1 The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "
Selection of Arbitrator Prior to arbitration, the complaining party shall cause the appointment of an AAA case manager by filing of a claim with the AAA along with the appropriate filing fee, and serving it on the defending party. The AAA case manager shall provide each party with a list of proposed arbitrators who meet the qualifications described below, or if no such person is available, who are generally familiar with the subject matter involved in the Dispute. Each side will have 14 days to strike any unacceptable names, number the remaining names in order of preference, and return the list to the AAA. The case manager shall then invite persons to serve from the names remaining on the list, in the designated order of mutual preference. Should this selection procedure fail for any reason, the AAA case manager shall appoint an arbitrator as provided in the applicable AAA Commercial Arbitration Rules.
Selection of Arbitrators There shall be three arbitrators. If there are only two parties to the Dispute, each party shall select one arbitrator within 15 days after receipt of a demand for arbitration. Such arbitrators may be affiliated or interested persons of such parties. If there are more than two parties to the Dispute, all claimants, on the one hand, and all respondents, on the other hand, shall each select, by the vote of a majority of the claimants or the respondents, as the case may be, one arbitrator within 15 days after receipt of a demand for arbitration. Such arbitrators may be affiliated or interested persons of the claimants or the respondents, as the case may be. If either a claimant (or all claimants) or a respondent (or all respondents) fail to timely select an arbitrator then the party (or parties) who has selected an arbitrator may request the AAA to provide a list of three proposed arbitrators in accordance with the Rules (each of whom shall be neutral, impartial and unaffiliated with any party) and the party (or parties) that failed to timely appoint an arbitrator shall have ten days from the date the AAA provides such list to select one of the three arbitrators proposed by AAA. If such party (or parties) fail to select such arbitrator by such time, the party (or parties) who have appointed the first arbitrator shall then have ten days to select one of the three arbitrators proposed by AAA to be the second arbitrator; and, if he/they should fail to select such arbitrator by such time, the AAA shall select, within 15 days thereafter, one of the three arbitrators it had proposed as the second arbitrator. The two arbitrators so appointed shall jointly appoint the third and presiding arbitrator (who shall be neutral, impartial and unaffiliated with any party) within fifteen (15) days of the appointment of the second arbitrator. If the third arbitrator has not been appointed within the time limit specified herein, then the AAA shall provide a list of proposed arbitrators in accordance with the Rules, and the arbitrator shall be appointed by the AAA in accordance with a listing, striking and ranking procedure, with each party having a limited number of strikes, excluding strikes for cause.
Certification of amounts A notice which is signed by 2 officers of a Creditor Party, which states that a specified amount, or aggregate amount, is due to that Creditor Party under this Clause 21 and which indicates (without necessarily specifying a detailed breakdown) the matters in respect of which the amount, or aggregate amount, is due shall be prima facie evidence that the amount, or aggregate amount, is due.
Consistent Legal Compliance The fact that certain provisions of this Agreement contain language which expressly requires compliance with all applicable laws, shall not give rise to an implication that other provisions, which do not expressly include such language, operate in derogation of the requirement for such legal compliance.
Notice of Arbitration If a Person asserts that there exists a Dispute, then such Person (the “Disputing Person”) will give each other Person involved in such Dispute a written notice setting forth the nature of the asserted Dispute. If all such Persons do not resolve any such asserted Dispute prior to the 10th business day after such notice is given, then any of them may commence arbitration pursuant to this Paragraph 19 by giving each other Person involved in such Dispute a written notice to that effect (an “Arbitration Notice”), setting forth any matters which are required to be set forth therein in accordance with the AAA Rules.
Notice of Impositions Lessor shall give prompt Notice to Lessee of all Impositions payable by Lessee hereunder of which Lessor at any time has knowledge, provided that Lessor’s failure to give any such Notice shall in no way diminish Lessee’s obligations hereunder to pay such Impositions, but such failure shall obviate any default hereunder for a reasonable time after Lessee receives Notice of any Imposition which it is obligated to pay during the first taxing period applicable thereto.
Notification by Agent The Agent shall, as promptly as practicable after the Bid Rate Quotes are submitted (but in any event not later than 10:30 a.m. (x) on the proposed date of borrowing, in the case of an Absolute Rate Auction or (y) on the date three Business Days prior to the proposed date of borrowing, in the case of a LIBOR Auction), notify the Borrower of the terms (i) of any Bid Rate Quote submitted by a Lender that is in accordance with Section 2.2.(c) and (ii) of any Bid Rate Quote that amends, modifies or is otherwise inconsistent with a previous Bid Rate Quote submitted by such Lender with respect to the same Bid Rate Quote Request. Any such subsequent Bid Rate Quote shall be disregarded by the Agent unless such subsequent Bid Rate Quote is submitted solely to correct a manifest error in such former Bid Rate Quote. The Agent’s notice to the Borrower shall specify (A) the aggregate principal amount of the Bid Rate Borrowing for which offers have been received and (B) the principal amounts and Absolute Rates or LIBOR Margins, as applicable, so offered by each Lender (identifying the Lender that made each Bid Rate Quote).
Appointment of Arbitrator Within thirty (30) days of service of a demand for arbitration by either party to this Agreement, the parties shall endeavor in good faith to select from the AAA list of labor and employment arbitrators a single arbitrator, who must be a licensed attorney; if the parties fail to do so within such thirty (30) day period, an arbitrator shall be selected in accordance with the AAA Rules.
