Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Notice of a Meeting Notice of a meeting called pursuant to Section 13.4 shall be given to the Record Holders of the class or classes of Units for which a meeting is proposed in writing by mail or other means of written communication in accordance with Section 16.1. The notice shall be deemed to have been given at the time when deposited in the mail or sent by other means of written communication.
Notice of Sale Each Pledgor acknowledges and agrees that, to the extent notice of sale or other disposition of the Pledged Collateral or any part thereof shall be required by law, ten (10) days’ prior notice to such Pledgor of the time and place of any public sale or of the time after which any private sale or other intended disposition is to take place shall be commercially reasonable notification of such matters. No notification need be given to any Pledgor if it has signed, after the occurrence of an Event of Default, a statement renouncing or modifying any right to notification of sale or other intended disposition.
Notice of Acceptance Notice of each Offeree’s intention to accept, in whole or in part, any Offer made shall be evidenced by a writing signed by such Offeree and delivered to the Company prior to the end of the 20-day period of such offer, setting forth such of the Offeree’s Basic Amount as such Offeree elects to purchase and, if such Offeree shall elect to purchase all of its Basic Amount, such Undersubscription Amount as such Offeree shall elect to purchase (the “Notice of Acceptance”). If the Basic Amounts subscribed for by all Offerees are less than the total Offered Securities, then each Offeree who has set forth Undersubscription Amounts in its Notice of Acceptance shall be entitled to purchase, in addition to the Basic Amounts subscribed for, all Undersubscription Amounts it has subscribed for; provided, however, that should the Undersubscription Amounts subscribed for exceed the difference between the Offered Securities and the Basic Amounts subscribed for (the “Available Undersubscription Amount”), each Offeree who has subscribed for any Undersubscription Amount shall be entitled to purchase only that portion of the Available Undersubscription Amount as the Undersubscription Amount subscribed for by such Offeree bears to the total Undersubscription Amounts subscribed for by all Offerees, subject to rounding by the Board of Directors to the extent it reasonably deems necessary.
Notice of Delay Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
Notice of Auction Results (a) On each Auction Date, the Auction Agent shall notify BD by telephone as set forth in paragraph (a) of the Settlement Procedures. On the Business Day next succeeding such Auction Date, the Auction Agent shall notify BD in writing of the disposition of all Orders submitted by BD in the Auction held on such Auction Date.
Notice of Non-Renewal If the Company or the Executive elects not to extend the Executive’s employment under this Agreement, the electing party shall do so by notifying the other party in writing not less than sixty (60) days prior to the expiration of the Initial Term, or sixty (60) days prior to the expiration of any Renewal Term. The Executive’s date of termination, for purposes of this Agreement, shall be the date of the Company’s last payment to the Executive. For the purposes of this Agreement, the election by the Company not to extend the Executive’s employment hereunder for any renewal term shall be deemed a termination of the Executive’s employment without “Cause,” as hereinafter defined.
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Notice Any notice required or permitted to be given by either party to the other shall be deemed sufficient if sent by registered or certified mail, postage prepaid, addressed by the party giving notice to the other party at the last address furnished by the other party to the party giving notice: if to the Issuer, at 00 Xxxxxxxxxx Xxxxxx, Xxxxxx, Xxxxxxxxxxxxx, and if to Distributors, at 00 Xxxxxxxxxx Xxxxxx, Xxxxxx, Xxxxxxxxxxxxx.
NOTICE OF ACCIDENTS 20.01 Tenant shall give notice to Landlord, promptly after Tenant learns thereof, of (i) any accident in or about the Demised Premises for which Landlord might be liable, (ii) all fires in the Demised Premises, (iii) all damages to or defects in the Demised Premises, including the fixtures, equipment and appurtenances thereof, for the repair of which Landlord might be responsible, and (iv) all damage to or defects in any parts or appurtenances of the Building’s sanitary, electrical, heating, ventilating, air-conditioning, elevator and other systems located in or passing through the Demised Premises or any part thereof.
