Notice by Successful Respondent Sample Clauses

Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DIR Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the DIR Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DIR Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DIR Customers and DIR Contractors.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Notice by Successful Respondent. Without limiting its obligations under this CTSA, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the Customers and DIR Contractors.
Sample 1Sample 2Sample 3See All (4)
Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DCS Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the DCS Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DCS Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DCS Customers and DIR Contractors.
Sample 1

Related to Notice by Successful Respondent

  • Notice of Successful Applicant The Employer shall, within three (3) calendar days, inform all applicants of the name of the successful applicant either in writing to each applicant or posting the name of the successful applicant in the same manner in which the vacancy or new job was posted.

  • Notification to Unsuccessful Job Applicants The parties agree that any unsuccessful candidate for an ONA job posting will be notified, in writing, within one (1) week of the decision being made and prior to the posting of the name of the successful candidate. The parties further agree that the above notification will be copied to the ONA Bargaining Unit President.

  • Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.

  • Conflict of Interest Questionnaire - Form CIQ No response Do not upload this form unless you have a reportable conflict with TIPS. There is an Attribute entitled “Conflict of Interest Questionnaire Requirement” immediately followed by an Attribute entitled “Conflict of Interest Questionnaire Requirement – Form CIQ – Continued.” Properly respond to those Attributes and only upload this form if applicable/instructed. If upload is required based on your response to those Attributes, the Conflict of Interest Questionnaire – Form CIQ must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded at this location. Vendor’s Warranties, Terms, and Conditions (Supplemental Vendor Information Only)

  • Entitlements for Successful Applicants (i) Orientation/Training: A registrant who accepts an offer of available work shall be entitled to a reasonable amount of orientation and/or training.

  • ONLY No response If proposing on Part 2, the vendor must download the Vendor Agreement from the attachment tab, fill in the requested information and upload the completed agreement. DO NOT UPLOAD encrypted or password protected files.

  • Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.

  • Notice of Hearing At least ten (10) days prior to the scheduled hearing, the claimant and his representative designated in writing by him, if any, shall receive written notice of the date, time, and place of such scheduled hearing. The claimant or his representative, if any, may request that the hearing be rescheduled, for his convenience, on another reasonable date or at another reasonable time or place.

  • Alternate or Supplemental Pricing Documents No response Optional. If when completing Pricing Form 1 & Pricing Form 2 you direct TIPS to view additional, alternate, or supplemental pricing documentation, you may upload that documentation.

  • Notice of Legal Matter or Litigation Grantee will send notice to the Substance Use Disorder (SUD) email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx of any litigation or legal matter related to or affecting this Contract within seven (7) calendar days of becoming aware of the litigation or legal matter.

Time is Money Join Law Insider Premium to draft better contracts faster.