NON-STADIUM ALTERNATIVE Sample Clauses

NON-STADIUM ALTERNATIVE. For the avoidance of doubt, the Parties acknowledge and agree that the Stadium Termination Event as described in section 5.3 of the DDA has occurred, provisions related to the Stadium Alternative in the DDA are no longer operative and the Parties are proceeding with development of the Non-Stadium Alternative under the DDA (as amended hereby), subject to the terms thereof. Section 1.2.2 of the DDA is hereby deleted and replaced with the following:
Sample 1Sample 2
AutoNDA by SimpleDocs
NON-STADIUM ALTERNATIVE. Schematic Design Documents: • Schematic Design Documents for the entire Northside Park including Parcels 1 and 2, the entire Waterfront Promenade North including Parcels 1 and 2, the entire Hunters Point Xxxxx Boulevard Park including Parcels 1and 2, Shipyard Hillside Open Space, and the entire Xxxxx Xxxxxxxx Neighborhood Park including Parcels 1 and 2 shall be submitted with the Major Phase Application for the Initial Major Phase. • Schematic Design Documents for the entire Cultural Heritage Park including Parcels 1 and 2, and Waterfront Promenade South Parcels 2A and 2B shall be submitted with the Major Phase Application for Major Phase 2. • Schematic Design Documents for, Waterfront Promenade South Parcels 1A and 1B, Shipyard South Park, Shipyard Wedge Park, Shipyard Neighborhood Park, Community Sports Fields Complex / Maintenance Yard, Shipyard Mini Park, Multi-Use Fields, Waterfront Recreation and Education Park, and the Regunning Crane Pier, Shipyard South Boulevard Park, Candlestick Point Neighborhood Park, Bayview Gardens, Wedge Park, Grasslands North, Boulevard Park North, Last Port, Candlestick Point Xxxx Boulevard Park including Parcels 1and 2, and Bayview Hillside Open Space and Jamestown Xxxxxx Slope shall be submitted with the Major Phase Application for Major Phase 3. • Schematic Design Documents for the Waterfront Promenade North Pier and Waterfront Promenade South Pier, Grassland Ecology Park North, Grassland Ecology Park South, Grasslands South, Boulevard Park South, The Neck, Mini-Wedge Park, The Last Rubble, Wind Meadow, The Heart of the Park, The Point, shall be submitted with the Major Phase Application for Major Phase 4.
Sample 1

Related to NON-STADIUM ALTERNATIVE

  • Capital Improvements The Department has identified the following possible opportunities for Capital Improvements:

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

  • Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

  • Initial Improvements It is currently contemplated that Tenant will construct prior to September 1, 2003, at Tenant's sole cost and expense, one or more Buildings, and all on and off site work, including landscaping (collectively referred to as "Initial Improvements"). The Initial Improvements, if constructed, shall in all events comply with the requirements of the PCP Permit ultimately issued by the City of Mountain View ("PCP"). Landlord hereby approves, subject to the terms and conditions of this Lease, Tenant's construction of the Initial Improvements so long as the exterior components thereof are generally in conformity with the PCP as such PCP is ultimately issued by the City of Mountain View. If Tenant desires to make any material changes to the exterior design of the Initial Improvements, then prior to submitting any application for amendment of the PCP to the City of Mountain View, Tenant shall deliver such proposed amendment to Landlord for Landlord's review and approval, which approval will not be unreasonably withheld or delayed. Any such disapproval must be in writing stating with particularity the reasons for such disapproval and the actions Tenant may take to modify such proposal in a manner that Landlord would approve. Landlord's failure to deliver such written disapproval within five (5) business days after Tenant has delivered such request for approval to Landlord shall be deemed Landlord's approval of such proposed amendment to the PCP. Landlord shall cooperate with Tenant as reasonably requested by Tenant with respect to any required governmental approvals, including, without limitation, any application for amendment of the PCP, in connection with the Initial Improvements, including the signing of any reasonable applications or requests which are required to be signed by the owner of the Project in order to obtain required approvals, provided that Landlord shall not be required to incur any costs or expenses or liability in connection therewith. Without limiting Landlord's discretion concerning its approval rights as to any amendments to the PCP that Tenant may reasonably request, the parties agree that (i) Tenant shall not, without Landlord's prior written consent, design or seek governmental approvals to construct more than 120,000 square feet of floor area (calculated as square footage is calculated by the City of Mountain View pursuant to the City of Mountain View Shoreline West Precise Plan) within the Initial Improvements, and (ii) the general design of the Initial Improvements shall be reasonably compatible, as reasonably determined by Landlord, with the design of the buildings to be constructed on the 13.48 acre parcel of property located on the opposite side of Amphitheater Parkway from the Project. Promptly following completion of the Initial Improvements, Tenant shall deliver to Landlord as built drawings thereof on original sepia drawn to 1/8" scale, prepared at Tenant's sole cost. Notwithstanding the foregoing, if Tenant fails to substantially complete construction of the Initial Improvements on or before September 1, 2003, then Landlord may, by written notice to Tenant delivered at any time after such date and prior to substantial completion of the Initial Improvements, elect to terminate this Lease, which termination shall be effective ninety (90) days following the date of delivery of such written notice to Tenant. Notwithstanding the foregoing, (i) if Tenant substantially completes the construction of the Initial Improvements prior to the expiration of such ninety-day period, then such termination notice shall be deemed rescinded, and (ii) if Tenant delivers to Landlord an Exercise Notice of the Purchase Option to purchase the Premises as contemplated in Paragraph 34 of this Lease, prior to the expiration of such 90-day period, then such termination notice shall be deemed suspended until the date upon which the closing pursuant to the Purchase Option is scheduled to occur under the terms of this Lease. If Tenant thereafter fails to perform its obligations under the Purchase Option after Tenant's delivery of the Exercise Notice for any reason other than Landlord's failure to perform its obligations with respect to the Purchase Option, then the termination notice earlier delivered to Tenant by Landlord shall be deemed reinstated, effective as of the business day following the scheduled date for such closing which did not occur.

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Selection of Architect/Construction Drawings Tenant shall retain the architect/space planner designated by Tenant and reasonably approved by Landlord (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.2. Tenant shall retain the engineering consultants selected by Tenant (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life safety, and sprinkler work in the Premises, which work is not part of the Base Building. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease shall specifically apply to the Construction Drawings.

  • Additional Work If changes in the work seem merited by Consultant or the City, and informal consultations with the other party indicate that a change is warranted, it shall be processed in the following manner: a letter outlining the changes shall be forwarded to the City by Consultant with a statement of estimated changes in fee or time schedule. An amendment to this Agreement shall be prepared by the City and executed by both Parties before performance of such services, or the City will not be required to pay for the changes in the scope of work. Such amendment shall not render ineffective or invalidate unaffected portions of this Agreement.

  • Capital Improvements and Expansion Subject to Section 3.5(b), any site or Premises renovation, expansion or reduction plans and/or capital equipment expenditures with respect to the Practice shall be reviewed and approved by the Joint Planning Board and shall be based upon economic feasibility, productivity and then current market conditions in light of both the particular project and the Group as a whole.

Time is Money Join Law Insider Premium to draft better contracts faster.