No Suspension of Work Sample Clauses

No Suspension of Work. 9.1 While this Agreement remains in effect, neither the Company nor the Union shall cause a suspension of work because of any differences or disputes that may arise between the two parties as to the interpretation of this Agreement.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
No Suspension of Work. The parties hereto agree that should differences arise between the Board and the Union as to the meaning and application of this Agreement, or should any other dispute arise, there shall be no suspension of work on account of such differences.
Sample 1Sample 2Sample 3See All (4)
No Suspension of Work. The Obligations of the Employer, the Engineer and Consultant shall not be altered by reasons of conciliation/arbitration being conducted during the progress of works. Neither party shall be entitled to suspend the work on account of conciliation/ arbitration and payments to Consultant shall continue to be made in terms of the contract.
Sample 1
No Suspension of Work. Should any dispute or grievance arise between the City and the Union, there shall be no suspension of work on the part of the Employer or Employees on account of such dispute or grievance. Grievances shall not be discussed when individual or group stoppages occur, until the employees participating in the stoppage, return to work.
Sample 1
No Suspension of Work. Notwithstanding the existence of any Dispute, including without limitation any Dispute with respect to the Work or compensation, unless and until this Agreement has been terminated in accordance with the terms and conditions herein, Contractor shall not delay or suspend any Work, and shall not be excused from any performance due under this Agreement. During any pending Dispute, Contractor shall perform and carry on all Work that is not in dispute at the Site or Sites affected by the Dispute and shall continue all Work at Sites other than the Site or Sites affected by the Dispute in accordance with the requirements of this Agreement.
Sample 1

Related to No Suspension of Work

  • Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide the Contractor written notice outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department.

  • No Suspension Trading in the Common Stock shall not have been suspended on the Exchange and the Common Stock shall not have been delisted from the Exchange.

  • Statement of Work The Contractor shall provide the services and staff, and otherwise do all things necessary for or incidental to the performance of work, as set forth below:

  • Description of Work (a) that has been omitted or

  • Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.

  • Suspension of Services We have the right to suspend the benefit of any Credit Union service at any time for reasonable cause. At Our discretion, We also have the right to pay any share draft presented for payment from Your Account after Your Account is closed or suspended and to recover such amount paid from You. Account services are available to those members in good standing with the Credit Union. We reserve the right to cancel or suspend services to a member who is not in good standing, which includes members that have: (a) a delinquent loan; (b) a primary Share Account balance below the $25.00 minimum; (c) an unresolved deposited returned check; (d) any unpaid and uncollected fees; or (e) a negative balance on an Account. ASSIGNABILITY. You may not assign or transfer any interest in Your Account.

  • Scope of Work The Contractor has overall responsibility for and shall provide and furnish all materials, equipment, tools and labor as necessary or reasonably inferable to complete the Work, or any phase of the Work, in accordance with the Owner’s requirements and the terms of the Contract Documents.

Time is Money Join Law Insider Premium to draft better contracts faster.