No Claim for Damages Sample Clauses

No Claim for Damages. Tenant hereby waives any claim against Landlord which Tenant may have based upon any assertion that Landlord has unreasonably withheld or delayed any consent or approval requested by Tenant, and Tenant agrees that its sole remedy shall be an action or proceeding to enforce any related provision or for specific performance, injunction or declaratory judgment. If there is a determination that such consent or approval has been withheld or delayed unreasonably, the requested consent or approval shall be deemed to have been granted; however, Landlord shall have no liability to Tenant for its refusal or failure to give such consent or approval.
Sample 1Sample 2
AutoNDA by SimpleDocs
No Claim for Damages. The Consultant agrees to make no claim for damages for delay in the performance of this Agreement occasioned by any act or omission to act of the Agency, or any of its members, directors, officers, employees, agents, contractors, subcontractors and/or representatives, and agrees that any such claim shall be fully compensated for by an extension of time to complete performance of the services as provided herein.
Sample 1
No Claim for Damages. A. The CONTRACTOR agrees to make no claim for damages for delay of reimbursement due to an act or omission by Oneida County, New York.
Sample 1
No Claim for Damages. Lessee's sole remedy for Lessor's refusal to -------------------- consent to a proposed assignee or sublessee of Lessee will be an action or proceeding for specific performance, injunction or declaratory judgment.
Sample 1
No Claim for Damages. If Mortgagor shall request Mortgagee's consent or approval pursuant to any of the provisions of this Mortgage or otherwise, and Mortgagee shall fail or refuse to give, or shall delay in giving, such consent or approval, Mortgagor shall in no event make, or be entitled to make, any claim for damages (nor shall Mortgagor assert, or be entitled to assert, any such claim by way of defense, set-off or counterclaim) based upon any claim or assertion by Mortgagor that Mortgagee unreasonably withheld or delayed its consent or approval, and Mortgagor hereby waives any and all rights that it may have from whatever source derived, to make or assert any such claim. Mortgagor's sole remedy for any such failure, refusal or delay shall be an action for a declaratory judgment, specific performance or injunction, and such remedies shall be available only in those instances where Mortgagee has expressly agreed in writing not to unreasonably withhold or delay its consent or approval or where, as a matter of law, Mortgagee may not unreasonably withhold or delay the same.
Sample 1
No Claim for Damages. Landlord agrees that whenever it is required to act pursuant to this Lease, it will do so in a reasonable manner. Tenant agrees that its sole remedy for any claim that Landlord has unreasonably withheld or unreasonably delayed any consent or approval requested by Tenant shall be an action or proceeding to enforce any related provision or for specific performance, injunction or declaratory judgment. In the event of a determination that such consent or approval has been withheld or delayed unreasonably, the requested consent or approval shall be deemed to have been granted; however, Landlord shall have no liability to Tenant for its refusal or failure to give such consent or approval. Tenant's sole remedy for Landlord's unreasonably withhold or delaying consent or approval shall be as provided in this Section 25.14.
Sample 1
No Claim for Damages. No claim for damages or any claim other than for an extension of time shall be made or asserted against the County because of any delays. No interruption, interference, inefficiency, suspension, or delay in the commencement or progress of the Work shall relieve the vendor of duty to perform, or give rise to any right to damages or additional compensation from the County. The vendor’s sole remedy shall be the right to seek an extension to the contract time. However, this provision shall not preclude recovery of damages by the vendor for hindrances or delays due solely to fraud, bad faith, or active interference on the part of the County.
Sample 1
AutoNDA by SimpleDocs

Related to No Claim for Damages

  • Procedures for Indemnification of Third Party Claims (a) If an Indemnified Party shall receive notice or otherwise learn of the assertion by a Person (including any Governmental Authority) who is not a member of the Vishay Group or the VPG Group of any claim or of the commencement by any such Person of any Action (collectively, a “Third Party Claim”) with respect to which an Indemnifying Party may be obligated to provide indemnification to such Indemnified Party pursuant to Section 5.2 or Section 5.3 or any other section of this Agreement or any Ancillary Agreement, such Indemnified Party shall give such Indemnifying Party written notice thereof within twenty (20) days after becoming aware of such Third Party Claim. Any such notice shall describe the Third Party Claim in reasonable detail. If any Person shall receive notice or otherwise learn of the assertion of a Third Party Claim which may reasonably be determined to be a Shared Contingent Liability, such Person shall give the other party to this Agreement written notice thereof within twenty (20) days after becoming aware of such Third Party Claim. Any such notice shall describe the Third Party Claim in reasonable detail. Notwithstanding the foregoing, the failure of any Indemnified Party or other Person to give notice as provided in this Section 5.6(a) shall not relieve the related Indemnifying Party of its obligations under this Article V, except to the extent that such Indemnifying Party is actually prejudiced by such failure to give notice.

  • Indemnification Exclusive Remedy In the absence of fraud, and -------------------------------- except for non-monetary equitable relief, if the Closing occurs, indemnification pursuant to the provisions of this Article 10 shall be the sole and exclusive remedy of the parties for any breach of any representation or warranty contained in this Agreement.

  • Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.

  • Action for Indemnification To indemnify Indemnitee for any expenses incurred by Indemnitee with respect to any action, suit or proceeding instituted by Indemnitee to enforce or interpret this Agreement, unless Indemnitee is successful in establishing Indemnitee’s right to indemnification in such action, suit or proceeding, in whole or in part, or unless and to the extent that the court in such action, suit or proceeding shall determine that, despite Indemnitee’s failure to establish their right to indemnification, Indemnitee is entitled to indemnity for such expenses; provided, however, that nothing in this Section 8(b) is intended to limit the Corporation’s obligation with respect to the advancement of expenses to Indemnitee in connection with any such action, suit or proceeding instituted by Indemnitee to enforce or interpret this Agreement, as provided in Section 4 hereof.

  • Third-Party Claim Indemnification Procedures (a) In the event that any written claim or demand for which an indemnifying party (an “Indemnifying Party”) may have liability to any Indemnified Party hereunder, other than those relating to Taxes (which are the exclusive subject of Article X), is asserted against or sought to be collected from any Indemnified Party by a third party (a “Third-Party Claim”), such Indemnified Party shall promptly, but in no event more than ten (10) days following such Indemnified Party’s receipt of a Third-Party Claim, notify the Indemnifying Party in writing of such Third-Party Claim, the amount or the estimated amount of damages sought thereunder to the extent then ascertainable (which estimate shall not be conclusive of the final amount of such Third-Party Claim), any other remedy sought thereunder, any relevant time constraints relating thereto and, to the extent practicable, any other material details pertaining thereto (a “Claim Notice”); provided, however, that the failure timely to give a Claim Notice shall affect the rights of an Indemnified Party hereunder only to the extent that such failure has a material prejudicial effect on the defenses or other rights available to the Indemnifying Party with respect to such Third-Party Claim. The Indemnifying Party shall have thirty (30) days (or such lesser number of days set forth in the Claim Notice as may be required by court proceeding in the event of a litigated matter) after receipt of the Claim Notice (the “Notice Period”) to notify the Indemnified Party that it desires to assume the defense of the Indemnified Party against such Third-Party Claim.

  • Claims for Indemnification Whenever any claim shall arise for indemnification under this Article V, Seller or Buyer, as the case may be, seeking indemnification (the “Indemnified Party”), shall notify the party from whom indemnification is sought in writing (the “Indemnifying Party”) of the claim within fourteen (14) days of the receipt of written notice of any such claim and, when known, the facts constituting the basis for such claim (an “Indemnification Claim Notice”). In the event of any such claim for indemnification hereunder resulting from or in connection with any claim or legal proceedings by a third party, the Indemnification Claim Notice shall specify, if known, the amount or an estimate of the amount of the liability arising therefrom and shall append all legal papers, notices and other documents received in connection therewith. The delivery of the Indemnification Claim Notice by the Indemnified Party to the Indemnifying Party within such fourteen (14) day period shall not be a condition precedent to any liability of the Indemnifying Party under this Agreement, unless such Indemnifying Party has otherwise been prejudiced by the lack of or delay in delivering such Indemnification Claim Notice. The Indemnified Party shall not settle or compromise any claim by a third party for which it is entitled to indemnification hereunder without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld or delayed if the settlement or judgment includes an unconditional release to the Indemnified Party from all liability with respect to such claim, provided, however, that if suit shall have been instituted against the Indemnified Party and the Indemnifying Party shall not have taken control of such suit after notification thereof as provided in Section 5.6 hereof, the Indemnified Party shall have the right to settle or compromise such claim upon giving reasonable and timely notice to the Indemnifying Party, as provided in Section 5.6.

  • Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • Defense of Infringement Claims In the event Licensee or Licensor becomes aware that Licensee’s or any of its Affiliates’ or any Sublicensees’ practice of the Licensed Patents is the subject of a claim for patent infringement by a Third Party, that Party shall promptly notify the other, and the Parties shall consider the claim and the most appropriate action to take. Licensee shall cause each of its Affiliates and each Sublicensee to notify Licensee promptly in the event such entity becomes aware that its practice of the Licensed Patents is the subject of a claim of patent infringement by another. To the extent Licensor takes any action, Licensor (or the ReGenX Licensors) shall have the right to require Licensee’s reasonable cooperation in any such suit, upon written notice to Licensee; and Licensee shall have the obligation to participate upon Licensor’s request, in which event, Licensor shall bear the cost of Licensee’s participation. Without Licensor’s prior written permission, Licensee must not settle or compromise any such suit in a manner that imposes any material obligations or restrictions on Licensor or the ReGenX Licensors or grants any rights to the Licensed Patents other than rights that Licensee has the right to grant under this Agreement.

  • Indemnification; Third Party Claims (a) The Special Servicer and any Affiliate, director, officer, employee, member, manager or agent of the Special Servicer (the “Special Servicer Indemnified Parties”) shall be indemnified and held harmless out of the proceeds of the Mortgage Loans, any Serviced Companion Loans and any B Notes (including REO Loans), against any and all claims, losses, penalties, fines, forfeitures, legal fees and related costs, judgments and any other costs, liabilities, fees and expenses (“Special Servicer Losses”) incurred in connection with any legal action relating to (i) this Agreement, any Mortgage Loans, any Serviced Companion Loans, any B Notes, any REO Property or the Certificates or any exercise of any right under this Agreement reasonably requiring the use of counsel or the incurring of expenses and (ii) any action properly taken by the Special Servicer in accordance with this Agreement based on an instruction delivered in writing to the Special Servicer by the Trustee, the Controlling Class Representative or the Master Servicer pursuant to any provision of this Agreement, and the Special Servicer and each of its Affiliates, directors, officers, employees, members, managers and agents shall be entitled to indemnification from the Trust for any loss, liability or expense (including attorneys’ fees) incurred in connection with the provision by the Special Servicer of any information included by the Special Servicer in the report required to be provided by the Special Servicer pursuant to this Agreement, in each case other than any loss, liability or expense: (A) specifically required to be borne by the party seeking indemnification, without right of reimbursement pursuant to the terms of this Agreement; (B) which constitutes a Servicing Advance that is otherwise reimbursable under this Agreement; (C) incurred in connection with any legal action or claim against the party seeking indemnification, resulting from any breach on the part of that party of a representation or warranty made in this Agreement; or (D) incurred in connection with any legal action or claim against the party seeking indemnification, resulting from any willful misfeasance, bad faith or negligence on the part of that party in the performance of its obligations or duties under this Agreement or negligent disregard of such obligations or duties. Except as provided in the following sentence, indemnification for Special Servicer Losses described in the preceding paragraph (including in the case of such Special Servicer Losses that relate primarily to the administration of the Trust, to any REMIC Pool or to any determination respecting the amount, payment or avoidance of any tax under the REMIC Provisions or the actual payment of any REMIC tax or expense) shall be paid out of collections on, and other proceeds of, the Mortgage Loans as a whole but not out of collections on, or other proceeds of, any Serviced Companion Loan or any B Note. In the case of any such Special Servicer Losses that do not relate primarily to the administration of the Trust, to any REMIC Pool or to any determination respecting the amount, payment or avoidance of any tax under the REMIC Provisions or the actual payment of any REMIC tax or expense:

Time is Money Join Law Insider Premium to draft better contracts faster.