New Pad Connections Sample Clauses

New Pad Connections. During the Minimum Volume Period, when Producers provide Notice under Section 6(a)(1) above, then Gatherer shall cause the necessary facilities to be constructed to tie-in such pad or pads to the applicable Xxxxxxx Gathering System subject to Producers complying with their obligations under Section 6(a)(1). Gatherer shall complete such facilities by the later of (x) the date of first production of such pad or pads with one or more Producer Xxxxx and (y) 21 Months after the date of Producers’ Notice (as the same may be extended pursuant to the following sentence, the “Completion Date”). If Gatherer is delayed in completing such facilities by (i) Force Majeure Events or (ii) the actions of Producers or their representatives that are inconsistent with the cooperation requirements of Section 6(a)(1) above, then the Completion Date for such connection shall be extended for a period equal to that during which Gatherer’s performance was precluded by such events or actions. If Gatherer fails to complete its facilities necessary to connect any such pad or pads to a Xxxxxxx Gathering System on or before the Completion Date for that pad or pads, as such Completion Date may be extended as provided above (the “Xxxxxxx Delayed Connections”), then the Producers, as their sole remedy for Gatherer failing to connect such Xxxxxxx Delayed Connections by the applicable Completion Date (but without limiting the following provisions of this Section 6(b)(1)), shall be entitled to a delay in their obligations with respect to the Adjusted Xxxxxxx Annual Minimum Volume under Section 4(d) of this Exhibit A for volumes of Producers’ Gas that would have been delivered from such Xxxxxxx Delayed Connections between the Completion Date for such Xxxxxxx Delayed Connections and the date on which such Xxxxxxx Delayed Connections are connected by Gatherer, as such delayed volumes are reasonably determined by Gatherer based on the type curve shown in Schedule 9. If at any time after Gatherer’s receipt of the notice from Producers regarding the connection of a new pad Gatherer becomes aware that it will not be able to connect such pad to the Xxxxxxx Gathering System (whether before or after the Completion Date for such pad) due to Force Majeure Events, then Gatherer shall provide Notice thereof to Producers as soon as practicable after becoming so aware and shall include with such Notice evidence that substantiates such inability to connect such pad (a “Pad Notice”). With respect to each pad c...
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
New Pad Connections. CEMI shall provide Gatherer prior Notice as soon as practicable of the expected date of first production for each new pad or pads with one or more Producer Xxxxx in the Xxxxxxx XXX. Such Notice to Gatherer shall include (i) the location of the pad or pads and xxxxx to be connected to the Xxxxxxx Gathering System, and (ii) the projected date of final completion and testing of such well or xxxxx to be connected to the Xxxxxxx Gathering System on such pad or pads. Following such Notice, Producers and Gatherer shall reasonably cooperate with each other in developing and providing to the other Party such other information and data regarding such pads and xxxxx reasonably requested by such Party, including, if requested by Gatherer, Producers’ good faith estimate of the Gas reserves for each such well or xxxxx and the projected monthly production profile for the first 5 Years after initial production for each such well or xxxxx. Because of the interrelated nature of the actions of the Parties required to obtain the necessary permits, authorizations, and rights of way from the appropriate state and local agencies and other Persons necessary to drill and complete each such well and construct the required extensions of the Xxxxxxx Gathering System to the pad or pads for such well or xxxxx, the Parties agree to work together in good faith to obtain such permits, authorizations, and rights of way as expeditiously as reasonably practicable, as provided herein. The Parties agree to cooperate with each other and to communicate regularly regarding their efforts to obtain such permits, authorizations, and rights of way.
Sample 1Sample 2See All (4)
New Pad Connections. When CEMI provides Notice under Section 6(a)(1) above after the end of the Minimum Volume Period, Gatherer, at its sole discretion, will determine whether the prevailing Xxxxxxx Fees at that time will allow it to earn an acceptable return on such connection and whether or not it will make the requested connection.
Sample 1Sample 2
New Pad Connections. When Producers provide Notice under Section 6(a)(1) above after the end of the Minimum Volume Period, Gatherer, at its sole discretion, will determine whether the prevailing Xxxxxxx Fees at that time will allow it to earn an acceptable return on such connection and whether or not it will make the requested connection.
Sample 1Sample 2

Related to New Pad Connections

  • Interconnection If Manager desires to interconnect a portion of the Service Area Network with another carrier and Sprint PCS can interconnect with that carrier at a lower rate, then to the extent permitted by applicable laws, tariffs and contracts, Sprint PCS may arrange for the interconnection under its agreements with the carrier and if it does so, Sprint PCS will xxxx the interconnection fees to Manager.

  • Infrastructure (a) The Borrower has and will maintain a sufficient infrastructure to conduct its business as presently conducted and as contemplated to be conducted following its execution of this Agreement.

  • Hardware and Software Requirements In order to access and retain Disclosures electronically, you must satisfy the following computer hardware and software requirements: access to the Internet; an email account and related software capable of receiving email through the Internet; a web browser which is SSL-compliant and supports secure sessions, and hardware capable of running this software.

  • Communications Equipment Members of the board of directors or any committee thereof may participate in and act at any meeting of such board or committee through the use of a conference telephone or other communications equipment by means of which all persons participating in the meeting can hear each other, and participation in the meeting pursuant to this section shall constitute presence in person at the meeting.

  • Rooftop Equipment Provided that Tenant complies with the terms of ----------------- this Section, Tenant may, at its risk and expense, install a satellite dish and related communications equipment and wiring (collectively, the "Rooftop ------- Equipment") on the roof of the Building at a location approved by Landlord, --------- which equipment may be used solely by Tenant and its Permitted Transferees or Permitted Sublessees. Before installing the Rooftop Equipment, Tenant shall submit to Landlord for its approval (which approval shall be in Landlord's sole discretion) plans and specifications which (a) specify in detail the design, location, size, and, in the case of a satellite dish, frequency of the Rooftop Equipment and (b) are sufficiently detailed to allow for the installation of the Rooftop Equipment in a good and workmanlike manner and in accordance with all Laws (the "Legal Requirements"). If Landlord approves of such plans, Tenant ------------------ shall install (in a good and workmanlike manner), maintain and use the Rooftop Equipment in accordance with all Legal Requirements and shall obtain all consents and permits required for the installation and operation thereof; copies of all such permits and evidence of such consents must be submitted to Landlord before Tenant begins to install the Rooftop Equipment. Tenant shall thereafter maintain all permits necessary for the maintenance and operation of the Rooftop Equipment while it is on the Building and operate and maintain the Rooftop Equipment in such a manner so as not to unreasonably interfere with any other satellite, antennae, or other transmission facility on the Building's roof or in the Building. Landlord may require that Tenant screen the Rooftop Equipment with a parapet or other screening device acceptable to Landlord. Tenant shall maintain the Rooftop Equipment and screening device in good repair and condition. Tenant shall, at its risk and expense, remove the Rooftop Equipment (including all wiring related thereto), within five days after the occurrence of any of the following events: (1) the termination of Tenant's right to possess the Premises; (2) the termination of the Lease; (3) the expiration of the Term; or (4)

  • Metering 1. If the Producer desires to sell electric power to the Company, the Company shall provide, own and maintain at the Producer's expense all necessary meters and associated equipment to be utilized for the measurement of energy and capacity for determining the Company's payment to the Producer pursuant to an applicable agreement.

  • External Hosting Facilities Transfer Agent shall implement controls, consistent with applicable prevailing industry practices and standards, regarding the collection, use, storage and/or disclosure of Fund Data by an external hosting provider.

  • Refinancing Facilities (a) At any time after the Closing Date, the Borrowers may obtain, from any Lender or any Additional Lender, Credit Agreement Refinancing Indebtedness in respect of (i) all or any portion of the Term Loans then outstanding under this Agreement (which, for purposes of this clause (i), will be deemed to include any then outstanding Other Term Loans and Other Term Loan Commitments) or (ii) all or any portion of the Revolving Loans (or unused Revolving Credit Commitments) under this Agreement (which, for purposes of this clause (ii), will be deemed to include any then outstanding Other Revolving Loans and Other Revolving Commitments), in the form of (x) Other Term Loans or Other Term Loan Commitments or (y) Other Revolving Loans or Other Revolving Commitments, as applicable, in each case, pursuant to a Refinancing Amendment; provided that such Credit Agreement Refinancing Indebtedness (A) shall rank pari passu in right of payment and of security with the other Loans and Commitments hereunder, (B) will have such pricing, fees, premiums, and interest or optional prepayment terms as may be agreed by the Borrowers and the Lenders thereof, (C)(x) with respect to any Other Revolving Loans or Other Revolving Commitments, will have a maturity date that is not prior to the maturity date of Revolving Loans (or unused Revolving Credit Commitments) being refinanced and (y) with respect to any Other Term Loans or Other Term Loan Commitments, will have a maturity date that is not prior to the maturity date of, and will have a Weighted Average Life to Maturity that is not shorter than, the then applicable Weighted Average Life to Maturity of the Term Loans being refinanced (other than to the extent of nominal amortization for periods where amortization has been eliminated or reduced as a result of prepayments of such Term Loans), (D) any Credit Agreement Refinancing Indebtedness in the form of Other Term Loans or Other Term Loan Commitments will share ratably in any voluntary and mandatory prepayments or repayments of Term Loans (unless the Lenders providing the Other Term Loans agree to participate on a less than pro rata basis in any voluntary or mandatory prepayments or repayments), (E) will, in the case of any Credit Agreement Refinancing Indebtedness in the form of Other Revolving Loans or Other Revolving Commitments, provide that (1) the borrowing and repayment (except for (i) payments of interest and fees at different rates on Other Revolving Commitments (and related outstandings), (ii) repayments required upon the maturity date of the Other Revolving Commitments and (iii) repayments made in connection with a permanent repayment and termination of commitments (subject to clause (3) below)) of Loans with respect to Other Revolving Commitments after the date of obtaining any Other Revolving Commitments shall be made on a pro rata basis with all other Revolving Credit Commitments, (2) subject to the provisions of Section 2.3 and Section 2.4 to the extent dealing with Swing Line Loans and Letters of Credit which mature or expire after a maturity date when there exists Incremental Revolving Credit Commitments with a longer maturity date, all Swing Line Loans and Letters of Credit shall be participated on a pro rata basis by all Lenders with Other Revolving Commitments in accordance with their percentage of the Revolving Credit Commitments (and except as provided in Section 2.3 and Section 2.4, without giving effect to changes thereto on an earlier maturity date with respect to Swing Line Loans and Letters of Credit theretofore incurred or issued), (3) the permanent repayment of Revolving Loans with respect to, and termination of, Other Revolving Commitments after the date of obtaining any Other Revolving Commitments shall be made on a pro rata basis with all other Revolving Credit Commitments, except that the Borrowers shall be permitted to permanently repay and terminate commitments of any such Class on a better than a pro rata basis as compared to any other Class with a later maturity date than such Class and (4) assignments and participations of Other Revolving Commitments and Other Revolving Loans be governed by the same assignment and participation provisions applicable to Revolving Credit Commitments and Revolving Loans, (F) such Credit Agreement Refinancing Indebtedness shall be subject to the Intercreditor Agreement and (G) will have terms and conditions that are not materially more restrictive, taken as a whole, to Holdings and its Restricted Subsidiaries than those applicable to the Refinanced Debt, taken as a whole, as determined in Holdings’ good faith judgment in consultation with the Administrative Agent (except for (A) covenants and events of default applicable only to periods after the Latest Maturity Date in effect at the time of the incurrence or issuance of any such Credit Agreement Refinancing Indebtedness or (B) unless the Borrowers enter into an amendment to this Agreement with the Administrative Agent (which amendment shall not require the consent of any other Lender) to add such more restrictive terms for the benefit of the Lenders). Each Class of Credit Agreement Refinancing Indebtedness incurred under this Section 2.26 shall be in an aggregate principal amount that is (x) not less than $10,000,000 in the case of Other Term Loans or $5,000,000 in the case of Other Revolving Loans and (y) an integral multiple of the Dollar Amount of $1,000,000 in excess thereof. Any Refinancing Amendment may provide for the issuance of Letters of Credit for the account of the Borrowers, or the provision to the Borrowers of Swing Line Loans, pursuant to any Other Revolving Commitments established thereby, in each case on terms substantially equivalent to the terms applicable to Letters of Credit and Swing Line Loans under the Revolving Credit Commitments.

  • Installation Tenant may install and use Tenant's Lines and make connections and disconnections at the terminal blocks as described above, provided Tenant shall: (i) obtain Landlord's prior written approval of all aspects thereof, (ii) use an experienced and qualified contractor designated or approved in writing in advance by Landlord (whom Landlord may require to enter an access and indemnity agreement on Landlord's then standard form of agreement therefor), (iii) comply with such inside wire standards as Landlord may adopt from time to time, and all other provisions of this Lease, including Paragraph 8 respecting alterations, and the Building rules respecting access to the wire closets, (iv) not install Lines in the same sleeve, chaseway or other enclosure in close proximity with electrical wire, and not install PVC-coated Lines under any circumstances, (v) thoroughly test any riser Lines to which Tenant intends to connect any Lines to ensure that such riser Lines are available and are not then connected to or used for telephone, data transmission or any other purpose by any other party (whether or not Landlord has previously approved such connections), and not connect to any such unavailable or connected riser Lines, and (vi) not connect any equipment to the Lines which may create an electromagnetic field exceeding the normal insulation ratings of ordinary twisted pair riser cable or cause radiation higher than normal background radiation, unless the Lines therefor (including riser Lines) are appropriately insulated to prevent such excessive electromagnetic fields or radiation (and such insulation shall not be provided by the use of additional unused twisted pair Lines). As a condition to permitting installation of new Lines, Landlord may require that Tenant remove any existing Lines located in or serving the Premises.

  • Projects 3.3.1 Exult Supplier shall perform the impact analysis as described in Section 4.

Time is Money Join Law Insider Premium to draft better contracts faster.