Milestone Deliverables Sample Clauses

Milestone Deliverables. The Critical Deliverables, Transition Milestones and Transformation Milestones (and related deliverables) are "Milestone Deliverables" for purposes of this Agreement. Other Deliverables may also be classified as Milestone Deliverables by the Parties if so agreed in writing. Each Milestone Deliverable shall be provided by Service Provider and subject to DIR (or, if designated in writing by DIR, DIR Customer's) "Acceptance" as described below in Section 4.6(b)(i) through (v).
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Milestone Deliverables. The Critical Deliverables are "Milestone Deliverables" for purposes of this Agreement. Other Deliverables may also be classified as Milestone Deliverables by the Parties if so agreed in writing. Each Milestone Deliverable shall be provided by Service Provider and subject to DIR (or, if designated in writing by DIR, Customer's) "Acceptance" as described below in Section 4.8(b)(i) through (v).
Sample 1Sample 2See All (5)
Milestone Deliverables. The Parties will submit the following “Milestone Deliverables,” “Delivery Dates,” and “Amounts” in the Web form at the “Business Terms” page for the Project on the Site: Milestone Deliverable Delivery Date Amount
Sample 1
Milestone Deliverables. The Parties will submit the following “Milestone Deliverables,” “Delivery Dates,” and
Sample 1
Milestone Deliverables. Licensee shall deliver to Platinum the following Milestone Deliverables for Platinum's written approval (subject to Paragraphs 11(b) and (c)): concept/treatment, design document, technical document, character models, material game builds and revisions, first playable version, Alpha, Beta and Gold Master candidate. Licensee shall also deliver to Platinum a Milestone Schedule in which descriptions for each Milestone Deliverable and the delivery dates for such Deliverables are set out, which Milestone Schedule shall mirror that which Licensee accepts from its Developer(s). With regard to the delivery dates for the final Deliverables of the Title, Licensee shall deliver the final Deliverables to Platinum in accordance with the Milestone Schedule. If Licensee fails to deliver the final Deliverables within three (3) months of the dates set out in the Milestone Schedule approved by Platinum, Platinum shall be entitled to terminate this Agreement in accordance with Paragraph 23. By way of clarification, Licensee shall have the opportunity to cure such non-delivery of the final Deliverable prior to any attempted termination provided that such later delivery of the final Deliverable permits the Title to be commercially released as provided herein.
Sample 1
Milestone Deliverables. ON Semiconductor will use commercially reasonable efforts to complete assigned Milestones according to the following timetable and as may be further detailed in each SOW: Milestone Description of Deliverable Associated NRE (USD) Committed Delivery Date Milestone 0 Development Agreement signed & project kick-off [***] T0(1) Milestone 1 [***] [***] T0 + [***] months Milestone 2 [***] [***] T0 + [***] months Milestone 3 [***] [***] T0 + [***] months Milestone 4 [***] [***] T0 + [***] months Milestone 5 [***] [***] T0 + [***] months Milestone 6 [***] [***] T0 + [***] months Total [***]
Sample 1
Milestone Deliverables. The Critical Deliverables and Transition Milestones are "Milestone Deliverables" for purposes of this Agreement. Other Deliverables may also be classified as Milestone Deliverables by the Parties if mutually agreed. Each Milestone Deliverable shall be provided by Successful Respondent and subject to DIR (or, if designated in writing by DIR, DIR Customer's) "Acceptance" as described below in Section 4.5(b)Error! Reference source not found. through (v). Specific Acceptance criteria may be contained within Exhibit 3.7, individual Work Orders, or in a Deliverables Expectation Document as described in Exhibit 3.3 Critical Deliverables.
Sample 1
AutoNDA by SimpleDocs
Milestone Deliverables 
Sample 1

Related to Milestone Deliverables

  • Deliverables Upon satisfactory completion of the work authorization, the Engineer shall submit the deliverables as specified in the executed work authorization to the State for review and acceptance.

  • Milestone Event Milestone Payment [***] [***]

  • Development Milestones In addition to its obligations under Paragraph 7.1, LICENSEE specifically commits to achieving the following development milestones in its diligence activities under this AGREEMENT: (a) (b).

  • Development Milestone Payments In partial consideration for the rights and licenses granted to Coya hereunder, within ten days after the first achievement of each milestone event in a given Indication set forth in this Section 5.2 (Development Milestone Payments) with respect to a Product (each, a “Development Milestone Event”) by or on behalf of Coya or any of its Affiliates or Sublicensees, Coya shall provide ARScience Bio written notice to ARScience Bio identifying the Development Milestone Event achieved. Upon receipt of any such notice of first achievement of a Development Milestone Event by Coya or its Affiliates or Sublicensees, ARScience Bio will promptly invoice Coya for the applicable Development Milestone Event and Coya will make a milestone payment to ARScience Bio in the amount set forth in this Section 5.2 (Development Milestone Payments) corresponding to such Development Milestone Event (each, a “Development Milestone Payment”) within 45 days of receipt of such invoice. On an Indication-by-Indication basis, each Development Milestone Payment shall be payable only upon the first achievement of the corresponding Development Milestone Event by a Product, in any given Indication for which the Development Milestone Events have not been previously achieved (each such Indication, a “New Indication”). No amounts shall be due for subsequent or repeated achievements of such Development Milestone Event with respect to the same or different Mono Product or Combination Product, as applicable, in such Indication. Accordingly and for clarity, the Development Milestone Payment shall be paid only once, when first achieved by Coya, an Affiliate or a Sublicensee, but no payment shall be due if the same milestone is subsequently achieved by one of Coya, an Affiliate or a Sublicensee. For clarity, the amounts owed in Column (a) below shall be due for the first Combination Product to achieve the Development Milestone Events in a New Indication and the amounts owned in Column (c) below shall be due for the first Mono Product to achieve the Development Milestone Events in a New Indication. Any Combination Product or Mono Product to achieve the Development Milestone Events in a New Indication after the first achievement of the Development Milestone Events as described in the foregoing sentence will cause the amounts in Column (b) with respect to a Combination Product and Column (d) with respect to a Mono Product to be due and payable by Coya upon each such occurrence. If the first Product to achieve a Development Milestone Event in any Indication is a Combination Product, the amounts in Column (a) below shall be due and payable by Coya. If the next Product to achieve a Development Milestone Event in a New Indication is a Mono Product, the amounts in Column (c) below would be due and payable by Coya; provided, that if such next Product to achieve a Development Milestone Event in a New Indication is a Combination Product, the amounts in Column (b) would be due and payable by Coya. By way of example, if a Combination Product achieves IND Acceptance in ALS, and is the first Product to achieve a Development Milestone Event under this Agreement, [***] will be due and payable by Coya. If subsequently a Mono Product achieves IND Acceptance in ALS, no Development Milestone Payments will be due and payable by Coya under this Agreement. However, if subsequently any Combination Product achieves IND Acceptance in Alzheimer’s disease, [***] would be due and payable by Coya.

  • Milestone A principal event specified in the Contract Documents including the Material Completion and Occupancy Date and other events relating to an intermediate completion date or time.

  • Milestones Subject to the provisions of the SGIP, the Parties shall agree on milestones for which each Party is responsible and list them in Attachment 4 of this Agreement. A Party’s obligations under this provision may be extended by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a Force Majeure event, it shall immediately notify the other Parties of the reason(s) for not meeting the milestone and (1) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (2) requesting appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not unreasonably withhold agreement to such an amendment unless it will suffer significant uncompensated economic or operational harm from the delay, (1) attainment of the same milestone has previously been delayed, or (2) it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.

  • Other Deliverables For any Deliverable that is not a System Deliverable, the applicable Work Order will set forth the acceptance criteria and other testing required for District to evaluate and accept (or, where necessary, reject) such Deliverable; provided, however, that in no case will a Deliverable be accepted by District until District has provided Contractor with District’s written acceptance thereof.

  • Commercial Milestone Payments For each Licensed Product, Licensee shall pay Arvinas the following one-time milestone event payments when the aggregate Net Sales of such Licensed Product in one or more particular country(ies) for a given calendar year (“Annual Net Sales”), where such Licensed Product is a Valid Claim Licensed Product at the time of sale in each of such country(ies), first achieves the corresponding threshold as set forth in this Section 6.3.2 below, subject to the terms of this Section 6.3 and the payment provisions in Article 7 below: Commercial Milestone Event Milestone Event Payment (US$)

  • Milestone Payment Within thirty (30) days following the first Patent Issuance, Eton shall give written notice to Imprimis and shall pay to Imprimis a non-refundable and noncreditable payment of fifty thousand dollars ($50,000).

  • Milestone Fees Licensee will pay Milestone Fees indicated in Section 3.1(b) of the Patent & Technology License Agreement by the Quarterly Payment Deadline for the Contract Quarter in which the milestone events set forth in Section 3.1(b) of the Patent & Technology License Agreement are achieved.

Time is Money Join Law Insider Premium to draft better contracts faster.