MEANS AND METHODS OF CONSTRUCTION. 4.1 Unless otherwise expressly provided in the Contract Drawings, Specifications, and Addenda, the Means and Methods of Construction shall be such as the Contractor may choose; subject, however, to the Engineer's right to reject the Means and Methods of Construction proposed by the Contractor which in the opinion of the Engineer:
MEANS AND METHODS OF CONSTRUCTION. Unless otherwise expressly provided in the contract drawings, specifications or bulletins, the means and methods of construction shall be such as the CONTRACTOR may choose; subject, however, to the OWNER’S right to prohibit means and methods proposed by the CONTRACTOR which in the OWNER’S judgment:
MEANS AND METHODS OF CONSTRUCTION. Unless otherwise expressly provided in the Contract Documents, the means and methods of construction shall be such as the Contractor may choose within trade and industry standards, subject, however, to the provisions of this Contract including, without limitation, the Scope of Work Documents (Part V) and the Drawings and Design Specifications (Part VI) of this Contract, and subject to the right of the Owner to reject means and methods proposed by the Contractor that will, in the opinion of the Owner:
MEANS AND METHODS OF CONSTRUCTION a. CONSULTANT shall not direct the means and methods of construction. CONTRACTOR shall be solely responsible for the means and methods of construction. Concerns or suggestions regarding the CONTRACTOR’s means and methods shall be communicated to CITY and ENGINEER.
MEANS AND METHODS OF CONSTRUCTION. The means and methods of construction shall be such as Contractor may choose; subject, however, to the City’s right to reject the Public Improvements for which the means or method of construction does not, in the judgment of the City Engineer, assure that the Public Improvements are constructed in accordance with Plans and Specifications.
MEANS AND METHODS OF CONSTRUCTION. 13.1 Unless otherwise expressly provided in this Agreement, the means and methods of construction shall be such as the Construction Manager may choose; subject, however, to the Director's right to reject means and methods proposed by the Construction Manager which: (1) will constitute or create a hazard to the Work, or to persons or property; or (2) will not produce finished Work in accordance with the terms of the Agreement.
MEANS AND METHODS OF CONSTRUCTION. A. Subject to those rights specifically reserved in the Contract Documents, Owner will not supervise, or direct, or have control over, or be responsible for, Contractor’s means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, or Contractor’s failure to comply with laws and regulations applicable to the furnishing or performance of Work. Owner will not be responsible for Contractor’s failure to perform or furnish the Work in accordance with Contract Documents.
MEANS AND METHODS OF CONSTRUCTION. (2) Defects or deficiencies in the work of the Contractors or delays in any of the work performed;
MEANS AND METHODS OF CONSTRUCTION. Irrespective of any other term in this Agreement, the Design Professional shall not control or be responsible for construction means, methods, techniques, schedules, sequences or procedures; or for construction safety or any other related programs; or for another parties’ errors or omissions; or for another parties’ failure to complete their work or services in accordance with the Design Professional’s documents.
MEANS AND METHODS OF CONSTRUCTION. Unless otherwise expressly provided in the Contract Documents and any amendments or additions thereto, the Work must be performed in accordance with the best modern practice, with new materials and workmanship of the highest quality, to the satisfaction of the City. The means and methods of construction shall be the Contractor's responsibility; subject, however, to the Project Manager’s right to reject any means and methods proposed or utilized by the Contractor that: (1) will constitute or create a hazard to the Work or to persons or property; or (2) will not produce the Work in the manner required by the Contract Documents. The Project Manager's approval of the Contractor's means and methods of construction, or his/her failure to exercise his/her right to reject such means or methods, shall not relieve the Contractor of its obligation to accomplish the result intended by the Contract Documents, nor shall any such rejection create a cause of action for damages.
