Liability for Damages Caused by Concurrent Negligence Sample Clauses

Liability for Damages Caused by Concurrent Negligence. Should a court of competent jurisdiction determine that this Contract is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injury to persons or damages to property caused by or resulting from the concurrent negligence of the Contractor and the City, its officers, officials, employees, and volunteers, the Contractor’s liability hereunder shall be only to the extent of the Contractor’s negligence. It is further specifically and expressly understood that the indemnification provided herein constitutes the Contractor’s waiver of immunity under Industrial Insurance, Title 51 RCW, solely for the purposes of this indemnification. This waiver has been mutually negotiated by the parties. The provisions of this section shall survive the expiration or termination of this Contract.
AutoNDA by SimpleDocs

Related to Liability for Damages Caused by Concurrent Negligence

  • Liability for other losses, damages etc Save and except as expressly provided in this Article, neither Party hereto shall be liable in any manner whatsoever to the other Party in respect of any loss, damage, cost, expense, claims, demands and proceedings relating to or arising out of occurrence or existence of any Force Majeure Event.

  • NO LIABILITY FOR DAMAGES In no event shall the author of this Software be liable for any special, consequential, incidental or indirect damages whatsoever (including, without limitation, damages for loss of business profits, business interruption, loss of business information, or any other pecuniary loss) arising out of the use of or inability to use this product, even if the Author of this Software is aware of the possibility of such damages and known defects.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Compensation for Damages and Losses Investors of either Contracting Party whose investments suffer losses in the territory of the other Contracting Party owing to war or other armed conflict, revolution, a state of national emergency or revolt, shall be accorded treatment by such other Contracting Party not less favourable than that which the latter Contracting Party accords to its own investors or to investors of any third State as regards restitution, indemnification, compensation or other valuable consideration.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

  • Liability for Damage Each party shall be liable to the other for all damage to the property of the other negligently, recklessly or intentionally caused by that party (or their agents, employees or invitees), except to the extent the loss is insured and subrogation is waived under the owner's policy.

  • No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.

  • NO LIABILITY FOR CONSEQUENTIAL DAMAGES In no event shall either Party be liable to the other Party for, and no arbitral panel is authorized to award, any punitive, special, indirect or consequential damages of any kind or character resulting from or arising out of this Agreement, including, without limitation, loss of profits or business interruptions, however they may be caused.

  • No Liability for Consequential Loss Except as otherwise expressly provided in Clauses 12.8 and 19.3(b), neither Party shall in any circumstances be liable to the other for (and the indemnities in Clauses 14.1 and 14.2 shall not extend to) any Consequential Loss.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the bidder hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

Time is Money Join Law Insider Premium to draft better contracts faster.