Liability for Breach of Contract 1. Any Party who violates the provisions of this Agreement and makes all or part of this Agreement unenforceable, shall be liable for breach of contract and shall compensate the other Party for the losses caused thereby (including the litigation fees and attorney fees caused thereby). If both Parties breach this Agreement, each shall bear the corresponding responsibility according to the actual situations.
Termination for Breach of Contract 1. Except as provided in PSC-6, if CONTRACTOR fails to perform any of the provisions of this Contract or so fails to make progress as to endanger timely performance of this Contract, CITY may give CONTRACTOR written notice of the default. CITY’S default notice will indicate whether the default may be cured and the time period to cure the default to the sole satisfaction of CITY. Additionally, CITY’S default notice may offer CONTRACTOR an opportunity to provide CITY with a plan to cure the default, which shall be submitted to CITY within the time period allowed by CITY. At CITY’S sole discretion, CITY may accept or reject CONTRACTOR’S plan. If the default cannot be cured or if CONTRACTOR fails to cure within the period allowed by CITY, then CITY may terminate this Contract due to CONTRACTOR’S breach of this Contract.
REMEDY FOR BREACH OF WARRANTY 3.1. Subject to the exclusions and limitations set out above, if the Product fails to comply with the Limited Warranty in clauses 1.2 or 1.3, BYD will repair or replace the non-conforming Product or parts thereof within the warranty term at no charge (or provide a partial refund) on the following conditions.
Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.
Breach of Agreement Failure by the party to comply with or perform any agreement or obligation (other than an obligation to make any payment under this Agreement or delivery under Section 2(a)(i) or 2(e) or to give notice of a Termination Event or any agreement or obligation under Section 4(a)(i), 4(a)(iii) or 4(d)) to be complied with or performed by the party in accordance with this Agreement if such failure is not remedied on or before the thirtieth day after notice of such failure is given to the party;
Damages for breach of maintenance obligations 17.8.1 In the event that the Concessionaire fails to repair or rectify any defect or deficiency set forth in the Maintenance Requirements within the period specified therein, it shall be deemed to be in breach of this Agreement and the Authority shall be entitled to recover Damages, to be calculated and paid for each day of delay until the breach is cured, at the higher of (a) 0.5% (zero point five per cent) of Performance Guarantee, and (b) 0.1% (zero point one per cent) of the cost of such repair or rectification as estimated by the Independent Engineer. Recovery of such Damages shall be without prejudice to the rights of the Authority under this Agreement, including the right of Termination thereof.
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
Liability for Breach 10.1 Either Party’s direct or indirect violation of any provisions hereof or failure to assume its obligations hereunder or failure to assume such obligations in a timely and adequate manner shall constitute breach of this Agreement. The non-breaching Party (“Non-Breaching Party”) shall have the right to require the breaching Party (“Breaching Party”) by written notice to redress its breach and take adequate, effective and timely measures to eliminate the consequences of such breach, and indemnify against the losses incurred by the Non-Breaching Party due to the breach of the Breaching Party.
No Breach of Contract The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.
Defendant’s Breach of Plea Agreement If the defendant commits any crimes, violates any conditions of release, or violates any term of this plea agreement between the signing of this plea agreement and the date of sentencing, or fails to appear for sentencing, or if the defendant provides information to the Probation Office or the Court that is intentionally misleading, incomplete, or untruthful, or otherwise breaches this plea agreement, the United States will be released from its obligations under this agreement. The defendant, however, will remain bound by the terms of the agreement, and will not be allowed to withdraw his plea of guilty. The defendant also understands and agrees that in the event he violates this plea agreement, all statements made by him to law enforcement agents subsequent to the execution of this plea agreement, any testimony given by him before a grand jury or any tribunal or any leads from such statements or testimony shall be admissible against him in any and all criminal proceedings. The defendant waives any rights that he might assert under the United States Constitution, any statute, Rule 11(f) of the Federal Rules of Criminal Procedure, Rule 410 of the Federal Rules of Evidence, or any other federal rule that pertains to the admissibility of any statements made by him subsequent to this plea agreement.
