LAYING OUT WORK Sample Clauses

The "Laying Out Work" clause defines the procedures and responsibilities for establishing the physical locations and dimensions of construction elements on a project site. It typically requires the contractor to accurately mark reference points, lines, and levels according to the project plans and specifications, often using surveying tools or benchmarks provided by the owner or architect. This clause ensures that all construction activities are based on precise measurements, minimizing errors and disputes related to the placement of structures, and ultimately helps maintain the integrity and alignment of the completed work.
LAYING OUT WORK. The CMR shall, upon entering the Project Site for the purpose of commencing the Work, locate all general reference points and take all such action as is necessary to prevent their destruction; lay out the Work, except where otherwise required by Contract Documents, and be responsible for all lines, elevations, measurements of buildings, grading, paving, utilities and other Work executed under the Contract. If benchmarks or other general reference points necessary for layout of the Work supplied by the Owner are impaired or destroyed by the CMR, the CMR shall be responsible at its cost to re-establish such bench marks or general reference points. The CMR shall exercise proper and reasonable care in verifying figures shown on the Drawings before laying out the Work and will be held responsible for any error resulting from its failure to exercise such care. The CMR shall establish permanent benchmarks referenced to finish floor lines. CMR shall employ a licensed surveyor who shall, after masonry corners have been set, certify on a drawing over its seal to the Owner that the building is located properly in relation to property lines and in accordance with the Drawings.
View SourceView Similar (7)
LAYING OUT WORK. A Locate all general reference points. Where dimensions or observed scope of work differ substantially from Drawings, notify Architect for decision. B Lay out Work from the reference points furnished and be responsible for all lines, elevations, and measurements inside workspace. Exercise proper precaution to verify figures shown on Drawings before laying out work and will be held responsible for any error resulting from his failure to exercise such precaution. C Call for public utility locates before starting any excavations. D Hire the services of a locator company to locate all privately owned utilities that may be disturbed by construction operations. E Coordinate utility connections with municipality/utility company in which project is being constructed.
View Source
LAYING OUT WORK. A. Carefully lay out work in advance of installation using data and measurements from the site, the appropriate architectural and structural drawings, and shop drawings. B. Confirm code required clearances. C. Do not infringe upon space required for operation, maintenance, or clearance for items installed by other contractors. ▇. ▇▇▇▇▇ to installation of any work, make certain the location does not conflict with other items in or near the same location. E. If the layouts so prepared indicate that the required conditions cannot be met in the space provided, inform the Engineer prior to installation and request clarification. F. Failure to properly coordinate and lay out work will require correction by the Contractor at the Contractor’s expense
View Source
LAYING OUT WORK. The Contractor shall, upon entering the Project Site for the purpose of commencing the Work, locate all general reference points and take all such action as is necessary to prevent their destruction; lay out the Work, except where otherwise required by Contract Documents, and be responsible for all lines, elevations, measurements of buildings, grading, paving, utilities and other Work executed under the Contract. If benchmarks or other general reference points necessary for layout of the Work supplied by the Owner are impaired or destroyed by the Contractor, the Contractor shall be responsible at its cost to re-establish such benchmarks or general reference points. The Contractor shall exercise proper and reasonable care in verifying figures shown on the Drawings before laying out the Work and will be held responsible for any error resulting from its failure to exercise such care. The Contractor shall establish permanent benchmarks referenced to finish floor lines. Contractor shall employ a licensed surveyor who shall, after masonry corners have been set, certify on a drawing over its seal to the Owner that the building is located properly in relation to property lines and in accordance with the Drawings.
View Source
LAYING OUT WORK a. The Contractor shall lay out his work correctly and shall be responsible for any damage caused to Owner or other contractors due to incorrect layout of his work. The Contractor shall engage and hire a licensed surveyor to locate the structures, to assure their correct and vertical position on the property, to establish correct levels and bench marks, to make required surveys for verifying boundary lines and easements, to locate column centers, piers, walls, pits and trenches and otherwise to fully and completely layout all work required by the Contract. b. The Drawings are intended to show correctly existing and contiguous work, but neither the Architect nor the Owner guarantees that such work will be executed in exact accordance with the Drawings. The Contractor shall, therefore, examine and verify any work in place or furnished by others upon which his work is in any way dependent for its perfect efficiency according to the intent of the Contract Documents, and shall at once report to the Architect and Owner any error or discrepancy which may appear in the same, so that any such matter may be explained or adjusted before the work in question is undertaken. In the event of the failure of the Contractor to give this notice before proceeding with his work, or if the Contractor shall connect his work to such erroneous work of other contractors, he shall assume all charges and make any changes to his work made necessary by his failure to observe this condition.
View Source

Related to LAYING OUT WORK

  • Working Out of Class Section 1 Whenever an employee is requested to perform the tasks of a higher graded position, that employee shall receive the rate of pay of that higher graded position, or five percent (5%) above his/her regular rate of pay, if the rate of pay for the higher graded position is less than five percent (5%) over and above that employee's regular rate of pay and his/her regular position, whichever is greater, for each and every hour worked in any higher grade during that contract year. Section 2 An employee temporarily assigned to a lower graded position shall be compensated at the rate of pay received in his/her regularly assigned job grade.

  • Moving Out a. Each Resident must remove all personal belongings from their room when the Occupancy period ends or this Contract is terminated. The room must be cleaned and notice made to REH staff for move out to be complete. Remaining personal items will be considered abandoned and will be sent to OSU Surplus for public auction or disposal. Residents will be charged for housing and dining until they have completed the entire move out process. More information about this process is available on our website: ▇▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/uhds/rates-policies/moving-out b. During move out, Residents may be present for an initial staff inspection of the final room condition; however, the initial inspection is informational in nature and is not the final determination of room condition. All rooms are inspected after the Resident vacates the room and this inspection may result in damage charges, regardless of whether the Resident is present at the time of inspection. c. The Resident agrees to pay for the cost of extra custodial service to remove personal belongings or to clean the room after the Resident has vacated. The Resident agrees that the University may determine these charges in its sole discretion and the University will calculate the charges to reasonably compensate for any damages based on its Common Residence Hall Charges Sheet, located at ▇▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/housing/rates-policies/room-dining-rates. d. Residents who do not intend to live on campus for Winter Term must vacate by 5:00 PM on December 10, 2021 and Residents who do not intend to live on campus for Spring Term must vacate by 5:00 PM on March 18, 2022. If a Resident fails to do this, they are subject to a $350 Extended Occupancy fee. e. Failure to vacate by the time and date required may result in charges calculated to reasonably compensate the University for damage incurred by the delay, in addition to prorated Room and Dining charges, unless the Resident withdraws from OSU- Cascades after the times and dates listed in Section 16(d). The Resident agrees to pay these term charges, available on the REH website: ▇▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/housing/rates-policies/room-dining-rates. f. If a Resident withdraws from OSU-Cascades and moves their belongings out, but has not completed the move out process, REH reserves the right to reassign the room to another resident. A failure to complete the move out process may result in University determined charges to reasonably compensate the University for damages as set forth in the Common Residence Hall Charges Schedule, located at ▇▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/housing/rates-policies/room-dining-rates.

  • Working Out of Classification Whenever an employee is assigned the principal duties and responsibilities of an employee in a higher classification for a single shift or greater period of time, that employee shall be paid a minimum of three (3) steps above their present salary, or shall receive the salary at the bottom of the range for the classification which they are working in, whichever is greater, for all such time worked.

  • Opting Out 6.1 The Opt-Out Deadline has Expired (1) The deadline to opt-out of the Proceedings expired on October 24, 2018, pursuant to Orders of the Ontario, BC and Québec Courts.

  • Appellate Court Orders to Vacate, Reverse, or Materially Modify Judgment If the reviewing Court vacates, reverses, or modifies the Judgment in a manner that requires a material modification of this Agreement (including, but not limited to, the scope of release to be granted by Class Members), this Agreement shall be null and void. The Parties shall nevertheless expeditiously work together in good faith to address the appellate court’s concerns and to obtain Final Approval and entry of Judgment, sharing, on a 50-50 basis, any additional Administration Expenses reasonably incurred after remittitur. An appellate decision to vacate, reverse, or modify the Court’s award of the Class Representative Service Payment or any payments to Class Counsel shall not constitute a material modification of the Judgment within the meaning of this paragraph, as long as the Gross Settlement Amount remains unchanged.