Landlord’s Performance of the Work Sample Clauses

Landlord’s Performance of the Work. Landlord shall be deemed authorized to proceed with the Initial Tenant Work shown on the Construction Documents on the fifth (5th) Business Day after Landlord submits to Tenant the price for the Excess Tenant Work Costs under Paragraph C.4, unless Tenant has then requested that Landlord delay the commencement of the Initial Tenant Work, in which event any such timely request (or any subsequent request) by Tenant to delay the work shall be subject to the provisions on Tenant Delay under Paragraph C.10 below. All Initial Tenant Work shall be performed and constructed by Landlord in accordance with the Construction Documents and in a good and workmanlike manner and in compliance with applicable Laws. With respect to any Initial Tenant Work Change Order submitted after Landlord is initially authorized (or deemed authorized) to proceed with the Initial Tenant Work, Landlord shall submit to Tenant a price estimate for such Change Order, and Landlord shall be deemed authorized to proceed with such Change Order on the fifth (5th) Business Day after submission of the price estimate to Tenant if the Change Order has not then been withdrawn. No Initial Tenant Work shall be performed except in accordance with the Construction Documents, and any Initial Tenant Work Change Orders, reasonably approved by Landlord. Landlord may require that the Construction Documents or any Initial Tenant Work Change Order be revised if, in Landlord’s reasonable judgment, (i) the requested work would delay completion of the Base Building Work or the Initial Tenant Work beyond the Estimated Term Commencement Date (unless Tenant acknowledges that such delay shall constitute a Tenant Delay under Paragraph C.10 below), (ii) would increase the cost of operating the Building or performing any other work in the Building (unless Tenant pays such additional costs), (iii) are incompatible with the design, quality, equipment or systems of the Building, or (iv) otherwise do not comply with the provisions of this Lease (including, without limitation, Section 8). Landlord shall not be responsible for any aspects of the design of the Initial Tenant Work, including the design of any Initial Tenant Work shown on any Initial Tenant Work Change Orders, with respect to the adequacy of the design for Tenant’s intended use of the Premises.
Sample 1See All (4)
AutoNDA by SimpleDocs
Landlord’s Performance of the Work. Landlord shall be deemed authorized to proceed with the Initial Tenant Work shown on the Construction Documents as of the Effective Date, unless Tenant has then requested that Landlord delay the commencement of the Initial Tenant Work, in which event any such timely request (or any subsequent request) by Tenant to delay the work shall be subject to the provisions on Tenant Delay under Paragraph C.10 below. All Initial Tenant Work shall be performed and constructed by Landlord in accordance with the Construction Documents and in a good and workmanlike manner and in compliance with applicable Laws. No Initial Tenant Work shall be performed except in accordance with the Construction Documents. Landlord may require that the Construction Documents be revised if, in Landlord’s reasonable judgment,(i) the requested work would delay completion of the Base Building Work or the Initial Tenant Work beyond the Estimated Term Commencement Date (unless Tenant acknowledges that such delay shall constitute a Tenant Delay under Paragraph C.10 below), (ii) would increase the cost of operating the Building or performing any other work in the Building (unless Tenant pays such additional costs), (iii) are incompatible with the design, quality, equipment or systems of the Building, or (iv) otherwise do not comply with the provisions of this Lease (including, without limitation, Section 8). Landlord shall not be responsible for any aspects of the design of the Initial Tenant Work with respect to the adequacy of the design for Tenant’s intended use of the Premises.
Sample 1Sample 2
Landlord’s Performance of the Work. Landlord hereby agrees, at Landlord’s sole cost and expense, to perform the work more particularly described on Schedule 1 attached hereto (the "Site and Shell Work"). The Site and Shell Work shall be performed in accordance with the plans referenced on Schedule 1 attached hereto and otherwise in a good and workmanlike manner and in compliance with all applicable Laws. The Site and Shell Work shall be deemed to be complete on the date all Site and Shell Work (other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use or occupancy of the Premises) has been performed as evidenced by the certificate of substantial completion prepared by the Landlord’s architect and issuance of the certificate of occupancy for the Building (or its equivalent). Completion shall have occurred even though minor details of construction, decoration, landscaping and mechanical adjustments remain to be completed, provided such items are completed within thirty (30) days after the Commencement Date. As part of the Site and Shell Work, Landlord shall provide an initial test fit for the Premises.
Sample 1

Related to Landlord’s Performance of the Work

  • Performance of Landlords Work (a) Definition of Landlord’s Work. As used herein, “

  • Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, the costs of code compliance work, if such work is required as a result of, or is a condition imposed by appropriate governmental authorities for, construction of the Tenant Improvements, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount which shall not exceed three percent (3%) of hard costs, utilities, and Landlord's Insurance Costs (including, without limitation, course of construction insurance), from the date of this Work Letter until the Lease Commencement Date up to a maximum of $450,000.00 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building, and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Tenant shall have the right to elect to increase the Tenant Improvement Allowance by up to an additional $450,000.00 (the "Additional Allowance"), subject to the following terms and conditions: (i) Tenant shall make such election, if at all, no later than August 15, 1998; (ii) such amount shall be paid to Landlord in equal monthly installments over the seven (7) year Lease Term with interest at 10%, as additional Base Monthly Rent in the manner specified by Article 3 of the Lease; and (iii) the Additional Allowance shall otherwise constitute a part of the Tenant Improvement Allowance and shall be subject to the restrictions and conditions on such Tenant Improvement Allowance provided in this Work Letter. Notwithstanding anything to the contrary contained herein or in the Lease, Landlord shall be responsible at its sole cost and expense for the incremental costs incurred by either Landlord or Tenant for asbestos removal within the interior of the Leased Premises required solely as a result of the construction of the Tenant Improvements. 5.

  • Performance by Landlord If Tenant fails to perform any obligation required under this Lease or by law or governmental regulation, Landlord in its sole discretion may, after ten (10) days prior written notice to Tenant, without waiving any rights or remedies and without releasing Tenant from its obligations hereunder, perform such obligation, in which event Tenant shall pay Landlord as additional rent all sums paid by Landlord in connection with such substitute performance, including interest at the Agreed Interest Rate (as defined in Section 19.J) within ten (10) days of Landlord's written notice for such payment.

  • Landlord’s Repair Obligations If this Lease does not terminate with respect to the entire Premises under Section 12.1, and if the Taking includes a portion of the Premises, then this Lease shall automatically terminate as to the portion of the Premises taken as of the date the Condemning Authority takes possession of the portion taken and Landlord will, at its sole cost and expense, restore the remaining portion of the Premises to a complete architectural unit with all commercially reasonable diligence and speed and will reduce the Basic Rent for the period after the date the Condemning Authority takes possession of the portion of the Premises taken to a sum equal to the product of the Basic Rent provided for in this Lease multiplied by a fraction, the numerator of which is the rentable area of the Premises after the Taking and after Landlord restores the Premises to a complete architectural unit, and the denominator of which is the rentable area of the Premises prior to the Taking. Landlord will also equitably adjust Tenant's Share of Expenses Percentage for the same period, subject to Section 3.7, to account for the reduction in the rentable area of the Premises or the Building resulting from the Taking. Tenant's obligation to pay Basic Rent and Tenant's Share of Expenses will xxxxx on a proportionate basis with respect to that portion of the Premises remaining after the Taking that Tenant is unable to use during Landlord's restoration for the period of time that Tenant is unable to use such portion of the Premises.

  • Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:

  • Landlord's Improvements All fixtures, improvements or equipment which are installed, constructed on or attached to the Premises or Common Area by Landlord shall be a part of the realty and belong to Landlord.

  • Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.

  • Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).

  • LESSEE'S IMPROVEMENTS Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.

  • TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.

Time is Money Join Law Insider Premium to draft better contracts faster.