INTERIM PAYMENT CERTIFICATE Sample Clauses

INTERIM PAYMENT CERTIFICATE. The Contractor shall forward to the Engineer an Interim Payment Certificate based on the statement as corrected above and, should it be necessary in the Engineers opinion, shall promptly make any further amendments and corrections to the Interim Payment Certificate. The Engineer shall not unreasonably withhold certifying an Interim Payment Certificate and in case of likely delay in establishing the value of an item, such item may be set aside and the remainder certified for payment. Within 45 days after receipt of the Interim Payment Certificate and subject to the Contractor having made such further amendments and corrections as the Engineer may require, the Engineer will forward to the Employer the certified Interim Payment Certificate. Provided that the Engineer shall not be bound to certify any payment under this Clause if the net amount thereof, after all retentions and deductions, would be less than the minimum amount of Interim Payment Certificate’s stated in the Appendix to Form of Bid. However in such a case, the uncertified amount will be added to the next interim payment, and the cumulative unpaid certified amount will be compared to the minimum amount of interim payment. SUBCLAUSE 60.3 – PAYMENT OF RETENTION MONEY A retention amounting to the percentage stipulated in the Appendix to Bid shall be made by the Engineer in the first and following Interim Payment Certificates until the amount retained shall reach the "Limit of Retention Money" named in the Appendix to Form of BID. Upon the issue of the Taking-Over Certificate, with respect to the whole of the works one half of the retention money shall become due and shall be paid to the Contractor when the Engineer shall certify in writing that the last section of the whole works has been substantially completed. Upon expiration of the Defects Liability Period for the works, the other half of the Retention Money shall be certified by the Engineer for payment to the Contractor. Provided that in the event of different Defects Liability Periods being applicable to different Sections of the Permanent Works pursuant to Clause 48, the expression “expiration of the Defects Liability Period “ shall, for the purpose of this sub-clause, be deemed to mean the expiration of the latest of such periods. Provided also that if at such time, there remain to be executed by the Contractor any work instructed, pursuant to Clause 49 and 50, in respect of the works, the Engineer shall be entitled to withhold certificatio...
Sample 1Sample 2Sample 3See All (45)
AutoNDA by SimpleDocs
INTERIM PAYMENT CERTIFICATE. The Contractor shall forward to the Engineer an Interim Payment Certificate based on the statement as corrected above and, should it be necessary in the Engineers opinion, shall promptly make any further amendments and corrections to the Interim Payment Certificate. The Engineer shall not unreasonably withhold certifying an Interim Payment Certificate and in case of likely delay in establishing the value of an item, such item may be set aside and the remainder certified for payment. Within 45 days after receipt of the Interim Payment Certificate and subject to the Contractor having made such further amendments and corrections as the Engineer may require, the Engineer will forward to the Employer the certified Interim Payment Certificate. Provided that the Engineer shall not be bound to certify any payment under this Clause if the net amount thereof, after all retentions and deductions, would be less than the minimum amount of Interim Payment Certificate’s stated in the Appendix to Form of Bid. However in such a case, the uncertified amount will be added to the next interim payment, and the cumulative unpaid certified amount will be compared to the minimum amount of interim payment.
Sample 1Sample 2Sample 3See All (16)
INTERIM PAYMENT CERTIFICATE. The Contractor shall forward to the Engineer an Interim Payment Certificate based on the statement as corrected above and, should it be necessary in the Engineers opinion, shall promptly make any further amendments and corrections to the Interim Payment Certificate. The Engineer shall not unreasonably withhold certifying an Interim Payment Certificate and in case of likely delay in establishing the value of an item, such item may be set aside and the remainder certified for payment.
Sample 1

Related to INTERIM PAYMENT CERTIFICATE

  • Replacement Certificates If, on the date a Securityholder’s escrow securities are to be released, the Escrow Agent holds a share certificate or other evidence representing more escrow securities than are to be released, the Escrow Agent will deliver the share certificate or other evidence to the Issuer or its transfer agent and request replacement share certificates or other evidence. The Issuer will cause replacement share certificates or other evidence to be prepared and delivered to the Escrow Agent. After the Escrow Agent receives the replacement share certificates or other evidence, the Escrow Agent will send to the Securityholder or at the Securityholder’s direction, the replacement share certificate or other evidence of the escrow securities released. The Escrow Agent and Issuer will act as soon as reasonably practicable.

  • Closing Certificate The Administrative Agent shall have received a certificate of each Loan Party, dated the Closing Date, substantially in the form of Exhibit C, with appropriate insertions and attachments.

  • Exhibit D - Debarment Certification By signing and submitting this Contract, the Contractor is agreeing to abide by the debarment requirements as set out below. • The certification in this clause is a material representation of fact relied upon by County. • The Contractor shall provide immediate written notice to County if at any time the Contractor learns that its certification was erroneous or has become erroneous by reason of changed circumstances. • Contractor certifies that none of its principals, affiliates, agents, representatives or contractors are excluded, disqualified or ineligible for the award of contracts by any Federal agency and Contractor further certifies to the best of its knowledge and belief, that it and its principals: • Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded by any Federal Department or Agency; • Have not been convicted within the preceding three-years of any of the offenses listed in 2 CFR 180.800(a) or had a civil judgment rendered against it for one of those offenses within that time period; • Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State, or Local) with commission of any of the offenses listed in 2 CFR 180.800(a); • Have not had one or more public transactions (Federal, State, or Local) terminated within the preceding three-years for cause or default. • The Contractor agrees by signing this Contract that it will not knowingly enter into any subcontract or covered transaction with a person who is proposed for debarment, debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction. • Any subcontractor will provide a debarment certification that includes the debarment clause as noted in preceding bullets above, without modification.

  • Cost Certification Redeveloper shall submit authentic documentation to the City on approved forms or format for payment of any expenses related to construction of the eligible Redeveloper Priority Expenses. Redeveloper shall timely submit receipts, invoices, or proof of payment concurrently with the request for reimbursement of eligible Redeveloper Priority Expenses. The City shall approve or reject the request for reimbursement with reasons stated, based on the review within ten (10) business days of receipt of the same. The foregoing notwithstanding, the City reserves the right during said ten (10) day period to request additional information and documentation related to a request for reimbursement from Redeveloper, and such a request by the City shall have the effect of restarting the ten (10) day period upon receipt of all requested information. Failure of the City to reject the request for reimbursement within said ten

  • Settlement Class Certification The Settling Parties agree, for purposes of this settlement only, to the certification of the Settlement Class. If the settlement set forth in this Settlement Agreement is not approved by the Court, or if the Settlement Agreement is terminated or cancelled pursuant to the terms of this Settlement Agreement, this Settlement Agreement, and the certification of the Settlement Class provided for herein, will be vacated and the Litigation shall proceed as though the Settlement Class had never been certified, without prejudice to any Person’s or Settling Party’s position on the issue of class certification or any other issue. The Settling Parties’ agreement to the certification of the Settlement Class is also without prejudice to any position asserted by the Settling Parties in any other proceeding, case or action, as to which all of their rights are specifically preserved.

Time is Money Join Law Insider Premium to draft better contracts faster.