Insurance against Injury to Persons and Damage to Property Sample Clauses

Insurance against Injury to Persons and Damage to Property. The insuring Party shall insure against each Party's liability for any loss, damage, death or bodily injury which may occur to any physical property (except things insured under Sub-Clause 18.2 [Insurance for Works and Contractor's Equipment]) or to any person (except persons insured under Sub-Clause 18.4 [Insurance for Contractor's Personnel), which may arise out of the Contractor's performance of the Contract and occurring before the issue of the Performance Certificate. This insurance shall be for a limit per occurrence of not less than the amount stated Contract Agreement, with no limit on the number of occurrences. If an amount t stated in the Contract, this Sub-Clause shall not apply. Unless otherwise stated in the Contract Agreement, the insurances specified in this Sub­Clause:
Sample 1Sample 2
AutoNDA by SimpleDocs
Insurance against Injury to Persons and Damage to Property. The Contractor shall take out and maintain insurance from the Effective Date until the later of the Certificate of Final Completion being issued and/or completion of the Operational Services in respect of each Party’s liability for any loss or damage to property, including without limitation the UNICEF’s, the Beneficiary’s and/or any third party’s property (other than the Works) and death and personal injury (other than to the Personnel), arising out of the Contractor’s performance of its obligations under this Contract in an adequate amount to cover all claims arising from or in connection with the Contractor’s performance of its obligations under this Contract and not less than the amount stated in the Particular Conditions and in the joint names of the Parties and any third party identified in the Particular Conditions.
Sample 1Sample 2
Insurance against Injury to Persons and Damage to Property. The insuring Party shall insure against each Party’s liability for any loss, damage, death or bodily injury which may occur to any physical property (except things insured under Sub-Clause 18.2 [
Sample 1
Insurance against Injury to Persons and Damage to Property. (a) The Service Provider shall insure against its liability for any loss, damage, death or bodily injury, or damage to any property which may arise out of the Service Provider’s performance of this Agreement.
Sample 1
Insurance against Injury to Persons and Damage to Property. Add the following paragraph after paragraph 2: The policy must specify that any employee of the Employer, the Engineer and his representatives, as well as the employees of any other company on the site are to be considered as third parties of the insurance policy. The insurance policies must include a clause forbidding their cancellation without the insurer giving prior notice to the Employer. The insurance company shall be a company licensed with the “Financial Services Commission" of Mauritius. Add the following words after “… under Sub-Clause 18.2) in line 2 of section (c), “and Employer’s personnel, including the Engineer and his representatives”
Sample 1
Insurance against Injury to Persons and Damage to Property. The insuring Party shall insure against each Party's liability for any loss, damage, death or bodily injury which may occur to any physical property (except things insured under Sub- Clause 23.2 [Insurance for Works and Contractor's Equipment]) or to any person (except persons insured under Sub-Clause 23.4 [Insurance for Contractor's Personnel]), which may arise out of the Contractor's performance of the Contract and occurring before the issue of the Making Good Defects Certificate/s. This insurance shall be for a limit per occurrence of not less than the amount stated in the Particular Conditions as amplified in the Feasibility Study and Financial Model, with no limit on the number of occurrences. If an amount is not stated in the Contract, this Sub-Clause shall not apply. Unless otherwise stated in the Particular Conditions or Schedule 4 as amplified in the Feasibility Study and Financial Model, the insurances specified in this Sub-Clause:
Sample 1
Insurance against Injury to Persons and Damage to Property. The Insuring Party shall insure against each Party's liability for any loss, damage, death or bodily injury which may occur to any physical property (except things insured under Sub-Clause 18.2 Insurance for Works and Contractor's Equipment]) or to any person (except persons insured under Sub-Clause 18.4 [Insurance for Contractor's Personnel]), which may arise out of the Contractor's performance of the Contract and occurring before the issue of the Performance Certificate. This insurance shall be for a limit per occurrence of not less than the amount stated in the Particular Conditions, with no limit on the number of occurrences. If an amount is not stated in the Particular Conditions, this Sub-Clause shall not apply. Unless otherwise stated in the Particular Conditions, the insurance's specified in this Sub-Clause:
Sample 1
AutoNDA by SimpleDocs
Insurance against Injury to Persons and Damage to Property. The Contractor shall, prior to the commencement of any Works, insure in an amount not being less than €10,000,000 (ten million Euros) against his liability for damage or death or personal injury occurring before the Works have been Taken-Over, to any person (including an employee of the Employer) or to any property (other than the property forming part of the Works) due to or arising out of the Works.
Sample 1

Related to Insurance against Injury to Persons and Damage to Property

  • LIMITATION ON LIABILITY; WAIVER OF PUNITIVE DAMAGES EACH OF THE PARTIES HERETO, INCLUDING BANK BY ACCEPTANCE HEREOF, AGREES THAT IN ANY JUDICIAL, MEDIATION OR ARBITRATION PROCEEDING OR ANY CLAIM OR CONTROVERSY BETWEEN OR AMONG THEM THAT MAY ARISE OUT OF OR BE IN ANY WAY CONNECTED WITH THIS AGREEMENT, THE LOAN DOCUMENTS OR ANY OTHER AGREEMENT OR DOCUMENT BETWEEN OR AMONG THEM OR THE OBLIGATIONS EVIDENCED HEREBY OR RELATED HERETO, IN NO EVENT SHALL ANY PARTY HAVE A REMEDY OF, OR BE LIABLE TO THE OTHER FOR, (1) INDIRECT, SPECIAL OR CONSEQUENTIAL DAMAGES OR (2) PUNITIVE OR EXEMPLARY DAMAGES. EACH OF THE PARTIES HEREBY EXPRESSLY WAIVES ANY RIGHT OR CLAIM TO PUNITIVE OR EXEMPLARY DAMAGES THEY MAY HAVE OR WHICH MAY ARISE IN THE FUTURE IN CONNECTION WITH ANY SUCH PROCEEDING, CLAIM OR CONTROVERSY, WHETHER THE SAME IS RESOLVED BY ARBITRATION, MEDIATION, JUDICIALLY OR OTHERWISE.

  • DAMAGE TO PROPERTY Exhibitor is liable for any damage caused to building floors, walls or columns, or to standard booth equipment, or to other Exhibitor’s property. Exhibitor may not apply paint, lacquer, adhesives, or other coating to building columns and floors or to standard booth equipment.

  • Partial Damage to Property (a) Tenant shall notify Landlord in writing immediately upon the occurrence of any damage to the Property. If the Property is only partially damaged (i.e., less than fifty percent (50%) of the Property is untenantable as a result of such damage or less than fifty percent (50%) of Tenant's operations are materially impaired) and if the proceeds received by Landlord from the insurance policies described in Paragraph 4.04(b) are sufficient to pay for the necessary repairs, this Lease shall remain in effect and Landlord shall repair the damage as soon as reasonably possible. Landlord may elect (but is not required) to repair any damage to Tenant's fixtures, equipment, or improvements.

  • Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.

  • Liability of Indemnitees (a) Notwithstanding anything to the contrary set forth in this Agreement, no Indemnitee shall be liable for monetary damages to the Partnership, the Limited Partners, or any other Persons who have acquired interests in the Partnership Interests, for losses sustained or liabilities incurred as a result of any act or omission of an Indemnitee unless there has been a final and non-appealable judgment entered by a court of competent jurisdiction determining that, in respect of the matter in question, the Indemnitee acted in bad faith or engaged in fraud, willful misconduct or, in the case of a criminal matter, acted with knowledge that the Indemnitee’s conduct was criminal.

  • Liability of Parties Without waiving any defenses including governmental immunity, each Party to this XXX agrees to be responsible for its own acts of negligence, which may arise in connection with any and all claims for damages, costs and expenses to person or persons and property that may arise out of or be occasioned by this XXX or any of its activities or from any act or omission of any employee or invitee of the Parties. The provisions in this paragraph are solely for the benefit of the Parties hereto and are not intended to create or grant any rights, contractually or otherwise to any third party.

  • Liability to Owners (i) Without prejudice to Sub-clause 17(a), the Managers shall be under no liability whatsoever to the Owners for any loss, damage, delay or expense of whatsoever nature, whether direct or indirect, (including but not limited to loss of profit arising out of or in connection with detention of or delay to the Vessel) and howsoever arising in the course of performance of the Management Services UNLESS same is proved to have resulted solely from the negligence, gross negligence or wilful default of the Managers or their employees or agents, or sub-contractors employed by them in connection with the Vessel, in which case (save where loss, damage, delay or expense has resulted from the Managers' personal actor omission committed with the intent to cause same or recklessly and with knowledge that such loss, damage, delay or expense would probably result) the Managers' liability for each incident or series of incidents giving rise to a claim or claims shall never exceed a total of ten (10) limes the annual management fee payable hereunder.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Limitation on Liability; Indemnification (a) Rise assumes no responsibility under this Agreement other than to render the services called for hereunder in good faith. Rise and its Affiliates, and any of their members, stockholders, managers, partners, personnel, officers, directors, employees, consultants and any person providing advisory or sub-advisory services to Rise, will not be liable to the Manager or the Manager’s stockholders, partners or members for any acts or omissions by any such Person (including errors that may result from ordinary negligence, such as errors in the investment decision making process or in the trade process) performed in accordance with and pursuant to this Agreement, except by reason of acts or omission constituting bad faith, willful misconduct, gross negligence or reckless disregard of their respective duties under this Agreement, as determined by a final non-appealable order of a court of competent jurisdiction. The Manager shall, to the full extent lawful, reimburse, indemnify and hold harmless Rise, its Affiliates, and any of their members, stockholders, managers, partners, personnel, officers, directors, employees, consultants and any person providing advisory or sub-advisory services to Rise (each, a “Rise Indemnified Party”), of and from any and all expenses, losses, damages, liabilities, demands, charges and claims of any nature whatsoever (including reasonable attorneys’ fees and amounts reasonably paid in settlement) (collectively “Losses”) incurred by the Rise Indemnified Party in or by reason of any pending, threatened or completed action, suit, investigation or other proceeding (including an action or suit by or in the right of the Manager or its security holders) arising from any acts or omissions of such Rise Indemnified Party performed in good faith under this Agreement and not constituting bad faith, willful misconduct, gross negligence or reckless disregard of duties of such Rise Indemnified Party under this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.