Infringement Claims – Indemnification by Seller Sample Clauses

Infringement Claims – Indemnification by Seller. Seller will defend, indemnify and hold harmless Buyer and its officers, directors, employees, agents and shareholders from any liabilities, losses, costs and expenses (including without limitation reasonable out of pocket expenses for attorneys’ fees and costs of litigation) (collectively “Losses”) arising out of a claim made against Buyer by a third party (but excluding claims described in Section 14 (b)) for alleged infringement of any U.S. patent, trademark or copyright existing as of the effective date of any Contract and relating to Buyer's lawful use of the Products purchased under such Contract in Buyer's business. Seller's obligations hereunder are contingent upon Buyer having made all payments to Seller then due at the time the claim arises and not otherwise being in breach of any provision of the Contract as well as Buyer’s complying with the Indemnification Procedures outlined below. Seller may also, at any time, at its option: (i) procure for Buyer the right to continue to use the Products in question, free of any liability for such infringement; or (ii) direct Buyer to cease use of and not market or sell such Products and (1) modify the Products in question so that they become non-infringing; (2) substitute the Products in question with functionally equivalent non-infringing Products; or (3) in accordance with Section 11 above, accept the return of the Products against payment of the Products’ then- depreciated value, computed on a three (3) year straight-line depreciation schedule commencing as of the date of delivery. The obligations set forth in this Section 14(a) shall be Buyer’s sole and exclusive remedy and Seller’s entire liability for any infringement of third party intellectual property rights as described in this Section 14(a).
Sample 1
AutoNDA by SimpleDocs
Infringement Claims – Indemnification by Seller. Seller will defend, indemnify and hold harmless Buyer and its officers, directors, employees, agents and equity holders from any liabilities, losses, costs and expenses (including without limitation reasonable out of pocket expenses for attorneys’ fees and costs of litigation) (collectively “Losses”) arising out of a claim made against Buyer by an unaffiliated third party (but excluding claims described in Section 16(b) or Section 17(a)) for alleged infringement of any U.S. patent, trademark or copyright existing as of the effective date of the Contract and relating to Xxxxx’s lawful use of the Products purchased under the Contract in Buyer’s business. Seller’s obligations hereunder are contingent upon Xxxxx having made all payments to Seller then due at the time the claim arises and not otherwise being in breach of any provision of the Contract, as well as Buyer’s compliance with the indemnification procedures outlined below. Seller may also, at any time, at its option: (i) procure for Buyer the right to continue to use the Products in question, free of any liability for such infringement; or (ii) direct Buyer to cease use of and not market or sell such Products and (1) modify the Products in question so that they become non-infringing;
Sample 1

Related to Infringement Claims – Indemnification by Seller

  • Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.

  • Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.

  • Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 13 and 14 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.

  • INDEMNITY FOR INFRINGEMENT CLAIMS EXCEPT TO THE EXTENT ARISING FROM MATERIALS PROVIDED TO CONTRACTOR BY UNIVERSITY, WHICH MATERIALS ARE UTILIZED BY CONTRACTOR IN THEIR UNALTERED FORM AND WITHOUT LIMITING THE GENERALITY OF THE INDEMNIFICATION CLAUSE REFERENCED IN THE HOLD HARMELSS SECTION BELOW, CONTRACTOR EXPRESSLY AGREES TO INDEMNIFY AND HOLD HARMLESS UNIVERSITY AND ITS DIRECTORS, OFFICERS, EMPLOYEES, AND AGENTS FROM AND AGAINST ANY AND ALL CLAIMS, SUITS, ACTIONS, LOSSES, LIABILITIES, COSTS, EXPENSES, AND DAMAGES ARISING OUT OF OR RELATED TO ANY CLAIMS THAT THE DELIVERABLES INFRINGE ANY PATENT, COPYRIGHT, TRADE SECRET, TRADEMARK, TRADE DRESS, MASK WORK, UTILITY DESIGN, OR OTHER PROPRIETARY RIGHT OF ANY THIRD PARTY. The indemnity under this Section will not apply to the extent such alleged or actual infringement arises as a result of (i) modifications of such work made by University which were not approved by Contractor, or (ii) Contractor’s compliance with any of University’s designs, specifications or instructions. In the event that a court of competent jurisdiction determines in a final, non-appealable order that the work is infringing in a manner for which Contractor is obligated to indemnify University pursuant to this Section, Contractor will, at its option, either (1) procure for University the right to continue using such infringing work; (2) replace the infringing work with a non-infringing item of like form, fit or function; or (3) modify the work so that it no longer infringes.

  • Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.

  • Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).

  • Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.

  • Infringement Claims You may submit an infringement claim notice to us at our Contact Formavailable here if you have a good faith belief that Your Content has been copied and made accessible through the Services (including as a part of the Service Content or Third Party Content) in violation of your Inte lectual Property Rights. A copyright infringement claims notice must include at (i) the identification of such a legedly infringing materials, including information su ficient for us to locate it within our Services, ( i) a demand that such a legedly infringing materials be removed or access disabled, ( i) a statement that you have a good faith belief that use of the material in the manner complained of is not authorized by the copyright owner, its agent, or the law; (iv) a statement that the information in the notification is accurate, and under penalty of perjury, that you are authorized to act on behalf of the owner of an exclusive right that is a legedly infringed; (v) contact information for you, such as address, phone number, and, if available, an email address; and (vi) must be signed by you or the person authorized to act on behalf of the owner of the a legedly infringed work (the “Notice Requirements”). Pursuant to 17 U.S.C. 512(c)(3), if the above Notice Requirements are not met, we may disregard the notice. Pursuant 17 U.S.C. 512(f), be advised that knowingly making a material misrepresentation that online material or activity is infringing or that material or activity was removed or disabled by mistake or misidentification, may subject you to heavy civil penalties. These penalties include monetary damages, including costs and attorneys' fees, incurred by the a leged infringer, by any copyright owner or copyright owner's authorized licensee, or by a service provider who is injured by your misrepresentation. If we make a decision to remove Your Content in response to a complaint, we may notify you and provide you with contact information for the complaining party. You may also object to such determination by writing to our designated agent, which must contain the fo lowing information pursuant to 17 U.S.C. 512(g)(3), (i) your physical or electronic signature; ( i) identification of the material that has been removed or to which access has been disabled and the location at which the material appeared before it was removed or access to it was disabled; ( i) a statement under penalty of perjury that the you have a good faith belief that the material was removed or disabled as a result of mistake or misidentification of the material to be removed or disabled; and (iv) your name, address, phone number, and a statement that you consent to the jurisdiction of Federal District Court for the judicial district in which the address is located, or if you are located outside of the United States, for any judicial district in which the service provider may be found, and that you wil accept service of process from the person who provided notification under subsection 17 U.S.C. 512(c)(1)(C) or an agent of such person.

  • PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.

  • Intellectual Property Indemnification Supplier agrees to defend, indemnify, and hold harmless DXC and its affiliates, subsidiaries, assigns, agents, subcontractors, distributors and customers (collectively “Indemnitees”) from and against all claims, losses, demands, fees, damages, liabilities, costs, expenses, obligations, causes of action, suits, or injuries, of any kind or nature, arising from: (i) any claim that Supplier’s Products or Services, or the use, sale or importation of them, infringes any intellectual property right. Without limiting the foregoing, Supplier will pay all costs, damages and expenses (including reasonable attorneys’ fees) incurred by DXC and/or its Indemnitees and will pay any award with respect to any such claim or agreed to in settlement of that claim.

Time is Money Join Law Insider Premium to draft better contracts faster.