Decisions of the Board The decision of the majority shall be the decision of the Board. Where there is no majority decision, the decision of the Chairperson shall be the decision of the Board. The decision of the Board of Arbitration shall be final and binding and enforceable on all parties, but in no event shall the Board of Arbitration have the power to change this Agreement or to alter, modify or amend any of its provisions. However, the Board shall have the power to dispose of any discharge or a discipline grievance by any arrangement which in its opinion it deems just and equitable.
Judicial Council 's Obligation Subject to Availability of Funds A. The Judicial Council's obligation under this Agreement is subject to the availability of authorized funds. The Judicial Council may terminate the Agreement or any part of the Contract Work, without prejudice to any right or remedy of the Judicial Council, for lack of appropriation of funds. If expected or actual funding is withdrawn, reduced, or limited in any way prior to the expiration date set forth in this Agreement, or in any Amendment hereto, the Judicial Council may, upon written Notice to the Contractor, terminate this Agreement in whole or in part. Such termination shall be in addition to the Judicial Council's rights to terminate for cause or other than for cause, as set forth herein.
Claims Subject to Mandatory Arbitration The following claims, if not settled through informal Dispute Resolution, will be subject to mandatory arbitration pursuant to Section 10.7 below:
Claims Subject to Arbitration Except as expressly provided below, the parties agree that to the fullest extent permitted by applicable law, any dispute arising out of or relating in any way to this Agreement or a similar prior agreement, the Property or the relationship between Resident and Owner or Manager (including matters occurring prior to the date of this Agreement and disputes also involving third parties) (collectively, “Claims”) will, at the election of either party, be resolved by arbitration, including any dispute about arbitrability, such as scope and enforceability.
Definitions and Other Provisions of General Application SECTION 101.
Claims Not Subject to Arbitration If the following claims are not resolved through informal Dispute Resolution, they will not be subject to arbitration and must be resolved through any remedy available to a Party pursuant to law, equity or agency mechanism.
Agreement Subject to CAISO Tariff The Parties will comply with all applicable provisions of the CAISO Tariff. This Agreement shall be subject to the CAISO Tariff which shall be deemed to be incorporated herein.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Provisions of the Agreement a reference to any Clause or Schedule is, except where it is expressly stated to the contrary, a reference to such clause of, or schedule to, this Agreement. A reference in a Schedule to any paragraph is, except where it is expressly stated to the contrary, a reference to a paragraph in that Schedule;
General Obligations of the Parties 33.2.1 The Parties must, at all times:
