Financial Requirements A report of monthly and cumulative financial requirements; and
General Federal Requirements 1. Grantee shall use such fiscal control and fund accounting procedures necessary to ensure the proper disbursement of, and accounting for, federal funds paid to the applicant under each such program.
TITLE VI REQUIREMENTS H-GAC in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Xxxx. 000, 00 X.X.X. §§ 0000x to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any disadvantaged business enterprises will be afforded full and fair opportunity to submit in response to this Agreement and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Special Requirements Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the “Special Requirements” attached hereto as Exhibit “B” and incorporated herein by this reference. In the event of a conflict between the provisions of Exhibit “B” and any other provisions of this Agreement, the provisions of Exhibit “B” shall govern.
Staff-to-Youth Ratio Requirement For all group activities the AGENCY shall abide by the staff-to-youth ratio range that is between the ratio established by its written policy and procedures and the ratio stated in Section 402.305(4), Florida Statutes. If the staff-to-youth ratio does not meet the minimum standard of care as stated in Section 402.305 (4), Florida Statutes, the AGENCY shall increase staff- to-youth ratios to meet these minimum standards. Section 402.305(4), Florida Statutes, states the minimum staff-to-youth ratio for on-site group activities for children five (5) years of age or older there must be one (1) childcare personnel staff to every twenty-five (25) children; for field trips and other off-site activities, Chapter 65C-22.001, Florida Administrative Code, requires one (1) extra adult, in addition to the on-site requirement. This standard shall be required for all programming paid for with funds under this Contract. The AGENCY will ensure that the staffing pattern is adequate and is adjusted to meet programmatic needs. The AGENCY shall adjust its staffing ratio to meet any ratio update required by Florida Statutes that occurs during the Contract year.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Sector Sub-Sector Industry Classification Level of Government Type of Obligation Description of Measure Source of Measure All sectors : : - : Central : National Treatment Senior Management and Board of Directors : National Treatment and the Senior Management and Board of Directors obligations shall not apply to any measure relating to small and medium sized domestic market enterprise2. Foreign equity is restricted to a maximum of 40% for domestic market enterprises with paid-in equity capital of less than the equivalent of USD 200,000 Note: Members of the Board of Directors or governing body of corporation or associations shall be allowed in proportion to their allowable participation or share in the capital of such enterprises. : -1987 Constitution of the Republic of the Philippines. - Foreign Investments Act of 1991 (R.A. No. 7042, as amended by R.A. No. 8179). -Presidential and Administrative Issuances. ∞ 2 The concept of a small and medium sized domestic market enterprise is an enterprise with paid in equity capital of less than the equivalent of USD 200,000.00.
U.S. Federal Procurement Requirements Without limiting Section 12.1, in light of DXC’s status as a U.S. Federal contractor and subcontractor, all applicable procurement regulations required by federal statute or regulation to be inserted in contracts or subcontracts apply to this Order, including but not limited to FAR 52.219-8 (Utilization of Small Business Concerns), FAR 52.219.-9 (Small Business Subcontracting Plan), FAR 52.219-16 (Liquidated Damages Subcontracting Plan), FAR 52.222-26 (Equal Opportunity), FAR 52.222-35 (Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and other Eligible Veterans), FAR 52.222-36 (Affirmative Action for Workers with Disabilities), FAR 52.222-39 ( Notification of Employee Rights Concerning Payment of Union Dues or Fees), FAR 52.222-41 (Service Contract Act of 1965), and FAR 52.247-64 (Preference for Privately Owned U.S. Flag Commercial Vessels).
Federal Requirements Pertaining to Grants and Subrecipient Agreements A. Requirement to Have a Single Audit: In the case that this Agreement is a Grant that is funded in whole or in part by federal funds, the Subrecipient will complete the Subrecipient Annual Report annually within 45 days after its fiscal year end, informing the State of Vermont whether or not a Single Audit is required for the prior fiscal year. If a Single Audit is required, the Subrecipient will submit a copy of the audit report to the granting Party within 9 months. If a single audit is not required, only the Subrecipient Annual Report isrequired. For fiscal years ending before December 25, 2015, a Single Audit is required if the subrecipient expends $500,000 or more in federal assistance during its fiscal year and must be conducted in accordance with OMB Circular A-133. For fiscal years ending on or after December 25, 2015, a Single Audit is required if the subrecipient expends $750,000 or more in federal assistance during its fiscal year and must be conducted in accordance with 2 CFR Chapter I, Chapter II, Part 200, Subpart F. The Subrecipient Annual Report is required to be submitted within 45 days, whether or not a Single Audit is required.
