General Condition Fee Sample Clauses

General Condition Fee. The Design-Build Firm's compensation for services performed during the Construction Phase shall be a Guaranteed Maximum Price (GMP) of $ . The Construction Phase Fee shall be paid in proportionate monthly payments for the percentage of Work performed that month less retainage. The first monthly payment shall become due thirty (30) days following the issuance of the Construction Phase Notice to Proceed by the County and the final monthly payment shall be paid only when Construction of the Project is Finally Completed and occupancy of i t is accepted by the County. If Construction is authorized only for a part of the Project, the fee paid shall be proportionate to the amount of work authorized by the County. Design-Build Firm's Exclusive Remedy: In the event the Construction Substantial or Final Completion date is extended, regardless of whether delay is caused by any act or neglect of the County, or is attributable to the County, the Design-Build Firm's sole and exclusive remedy is an extension of the Construction completion date.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs

Related to General Condition Fee

  • General Condition The Aircraft will:

  • General Conditions (i) Each party will make each payment or delivery specified in each Confirmation to be made by it, subject to the other provisions of this Agreement.

  • General Conditions Costs Construction Manager is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from the Owner through Substantial Completion of the Project plus thirty (30) calendar days. Construction Manager is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion must be approved in advance by the Owner. Allowable General Conditions items are identified below and by attached exhibit. These items shall be included in the General Conditions cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the schedule of values. Items not specifically included below or in the exhibit will not be allowed as a General Condition costs.

  • For General Conditions Costs Contractor’s Application for Payment shall be submitted on a Schedule of Values approved by the Owner and include complete copies of all receipts, invoices with check vouchers or other evidence of payment, payrolls, and any and all other evidence which Owner or its designated representatives shall deem necessary to support the amount requested. This information is subject to audit and payment for these costs is dependent on Owner’s receipt of accurate and complete records of all transactions. Owner may reduce the amount requested for General Conditions Costs in any Application for Payment if Owner, in its good faith judgment, determines that the unpaid balance of the General Conditions line item in the Schedule of Values is not sufficient to fund necessary General Conditions Costs for the remainder of the Project.

  • – OTHER SPECIAL CONDITIONS The following additional special conditions apply to this agreement:

  • SPECIAL CONDITIONS A submitted appeal must;

  • Additional Conditions For each mediation or arbitration:

  • General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades,

Time is Money Join Law Insider Premium to draft better contracts faster.