Work Schedule Within ten (10) days after the execution of this Lease, Landlord will deliver to Tenant, for Tenant's review and approval, a schedule ("Work Schedule") which will set forth the timetable for the planning and completion of the installation of the Tenant Improvements and the Commencement Date of the Lease. The Work Schedule will set forth each of the various items of work to be done or approval to be given by Landlord and Tenant in connection with the completion of the Tenant Improvements. The Work Schedule will be submitted to Tenant for its approval, which approval Tenant agrees not to unreasonably withhold, and, once approved by both Landlord and Tenant, the Work Schedule will become the basis for completing the Tenant Improvements. All plans and drawings required by this Work Letter Agreement and all work performed pursuant thereto are to be prepared and performed in accordance with the Work Schedule. Landlord may, from time to time during construction of the Tenant Improvements, modify the Work Schedule as Landlord reasonably deems appropriate. If Tenant fails to approve the Work Schedule, as it may be modified after discussions between Landlord and Tenant within five (5) business days after the date the Work Schedule is first received by Tenant, the Work Schedule shall be deemed to be approved by Tenant as submitted or Landlord may, at its option, terminate the Lease upon written notice to Tenant.
Project Schedule Contractor shall perform the Work in accordance with the Project Schedule.
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
Annual Operating Plan Manager shall implement the Operating Plan prepared by Owner. The Operating Plan shall constitute a standard to which Manager shall reasonably attempt to adhere in the operation of the Project; provided, however, as the Operating Plan is a budget, Manager makes no representation or warranty that the actual operations of the Project shall conform to such plan. Except in an emergency, Manager shall not expend funds in any fiscal year in excess of the budgeted line item amounts in the Operating Budget without Owner's prior written approval. In the event any Fiscal Year shall commence without an approved Operating Plan, until the Operating Plan for such Fiscal Year is approved, Manager shall be entitled to make expenditures for items specified in the approved Operating Plan for the past Fiscal Year, at a rate not in excess of the rate permitted under that prior Operating Plan (other than for utilities, taxes, insurance premiums and mortgage payments), without the prior consent of Owner.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Development Schedule The schedule for design and development of the "BASE BUILDING WORK" (as defined below) and the "TENANT IMPROVEMENTS" (as defined below), including, without limitation, the time periods for preparation, delivery, review, and approval of construction documents and performance pursuant to such documents, shall be in accordance with the Development Schedule attached hereto as Schedule A, subject to adjustment as mutually agreed by the parties in writing or as provided in this Work Letter (the "DEVELOPMENT SCHEDULE").
Tenant Improvement Plans Any work proposed by Tenant at the Premises or Building (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit, which approval shall not be unreasonably withheld or delayed except for good cause shown. All architectural, engineering and other design fees shall be paid by Tenant, provided that, of the total Tenant Improvement Allowance, up to Five and No/100 Dollars (S5.00) per rentable square foot of the Premises of such fees may be subject to reimbursement under the Tenant Improvement Allowance. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Santa Xxxxx and the State of California. Tenant shall cause its architect, who shall be subject to Landlord’s prior approval (“Tenant’s Architect”), which approval shall not be unreasonably withheld or delayed except for good cause shown, to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld or delayed) within twenty-one (21) days following mutual execution of the Lease. (If available upon mutual execution of this Lease, a mutually-approved preliminary space plan for the Tenant Improvements has been attached hereto as Exhibit C-1.) Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan, and Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval within five (5) business days thereafter. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval within sixty (60) days following Landlord’s approval of the final Space Plan. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion as supported by statement or reports from licensed engineers, the work, as described in any such item: (i) will adversely affect Building systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) will materially impair Landlord’s ability to furnish services to Tenant or other tenants at the Project; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances not permitted under Applicable Laws; (vi) would affect the external appearance of the Building; (vii) would materially and adversely affect another tenant’s premises at the Project: or (viii) is prohibited by any mortgage, trust deed or other instrument encumbering the Building or Project. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, and Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval within ten (10) business days thereafter. Such process shall continue until Landlord has approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Operating Plan To Agent and Lenders, as soon as available, but not later than thirty (30) days after the end of each Fiscal Year, an annual combined operating plan (the "Operating Plan") for Parent and its Subsidiaries, approved by the Board of Directors of Parent, for the following Fiscal Year, which (i) includes a statement of all of the material assumptions on which such plan is based, (ii) includes projected monthly income statement, balance sheets and source and use of funds for the following year and (iii) Borrowing Availability projections, all prepared on the same basis and in similar detail as that on which operating results are reported (and in the case of cash flow projections, representing management's good faith estimates of future financial performance based on historical performance), and including plans for personnel, Capital Expenditures and facilities.
Annual Operating Budget As soon as available but, in any event, within sixty (60) days prior to (i) the Cooperation Period Commencement Date in respect of the initial Plant to be completed and, thereafter, (ii) the commencement of each Fiscal Year, an annual operating budget (the "Annual Budget") (including budgeted statements of income and sources and uses of cash and balance sheets) prepared by the Borrower and accompanied by a statement of the chief financial officer of the Borrower to the effect that, the best of his or her knowledge, the budget is a reasonable estimate for the period covered thereby. The first Annual Budget shall cover the period from the Cooperation Period Commencement Date through the end of the Fiscal Year in which the Cooperation Period Commencement Date occurs, and, if such period consists of less than six (6) months, for the immediately succeeding Fiscal Year. Each Annual Budget shall contain complete, fair and accurate estimates (by principal components) of Sales Proceeds, Operating and Maintenance Costs and Debt Service for each Month covered by such Annual Budget based on the Borrower's best projections at such time. Unless otherwise consented to by Eximbank, the Annual Budget from year to year shall be based on the same format as the Base Case Forecast, including any amounts allocated for contingencies, and be maintained on the same basis and provide sufficient detail to permit a meaningful comparison. For each Annual Budget that is expected to cover any period occurring after the Disbursement Date, Eximbank (in consultation with the Independent Engineer) shall review such Annual Budget, and Eximbank's response shall not be unreasonably delayed. If Eximbank does not approve an Annual Budget, Eximbank shall notify the Borrower of the items which are disapproved and the reason for such disapproval. Until such Annual Budget is so approved, the Annual Budget most recently in effect shall continue to apply, except that any items of the then proposed Annual Budget that have been approved shall also be given effect. From time to time, but not more frequently than once per Quarter, the Borrower may propose amendments to an Annual Budget, and Eximbank (in consultation with the Independent Engineer) may reject such proposal within thirty (30) Business Days from the date the Borrower submits such proposal if in Eximbank's reasonable judgment such amendment is not reasonably necessary or advisable for operation of the Project and, if no such rejection is made, such amendments shall become effective. Not later than three (3) Business Days after the effective date of each Annual budget and of any amendment thereto, the Borrower shall provide a copy of the same to the Collateral Trustee.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
