FINANCIALLY SOLVENT. Contractor represents and warrants that Contractor has not commenced bankruptcy proceedings and that there are no judgment, liens, or encumbrances of any kind affecting title to any Goods or Services that are the subject of this Master Contract.
FINANCIALLY SOLVENT. Vendor warrants that it is financially solvent, is able to pay all debts as they mature and is possessed of sufficient working capital to complete all Services and perform all obligations under this Agreement.
FINANCIALLY SOLVENT. Provider warrants that it is financially solvent, is able to pay all debts as they mature and is possessed of sufficient working capital to complete all Services, deliver all Products, and perform all obligations under this Agreement.
FINANCIALLY SOLVENT. Contractor represents and warrants that Contractor has not commenced bankruptcy proceedings and that there are no judgment, liens, or encumbrances of any kind affecting title to any Goods and/or Services that are the subject of this Contract. Operational Capability. Contractor represents and warrants, as previously certified in Contractor’s Bidder’s Certification, that Contractor has the operational and financial capability to perform the Contract. Contract Transition. Contractor represents and warrants that, in the event this Contract is transitioned to another contractor (e.g., Contract expiration or termination), Contractor shall use commercially reasonable efforts to assist [AGENCY] for a period of sixty (60) days to effectuate a smooth transition to another contractor to minimize disruption of service and/or costs to the State of Washington. [Placeholder]. Contractor represents and warrants, as previously certified in Contractor’s Bidder’s Certification, that Contractor __________.
FINANCIALLY SOLVENT. Contractor represents and warrants that Contractor has not commenced bankruptcy proceedings and that there are no judgment, liens, or encumbrances of any kind affecting title to any Goods and/or Services that are the subject of this Contract. Operational Capability. Contractor represents and warrants, as previously certified in Contractor’s Bidder’s Certification, that Contractor has the operational and financial capability to perform the Contract. Contract Transition. Contractor represents and warrants that, in the event this Contract is transitioned to another contractor (e.g., Contract expiration or termination), Contractor shall use commercially reasonable efforts to assist DSB for a period of sixty (60) days to effectuate a smooth transition to another contractor to minimize disruption of service and/or costs to the State of Washington.
FINANCIALLY SOLVENT. Sellers are, and as of the Closing Date will be, financially solvent and able to pay their debts as they fall due.
FINANCIALLY SOLVENT. Purchasers are, and as of the Closing Date will be financially solvent and able to pay their debts as they become due.
FINANCIALLY SOLVENT. Vendor warrants that it is financially solvent, is able to pay all debts as they This Agreement will be posted on the CPS website. mature and is possessed of sufficient working capital to complete all Services and perform all obligations under the Contract.
FINANCIALLY SOLVENT. Contractor warrants that it is financially solvent, is able to pay all debts as they mature and is possessed of sufficient working capital to complete all Services and perform all obligations under this Agreement.
FINANCIALLY SOLVENT. Member is financially solvent and is able to pay all debts as they mature. Member also warrants that it does not owe any non-tax debt to the federal government including but not limited to the FCC.
