Final Drawings and Specifications Sample Clauses

Final Drawings and Specifications. The Architect shall prepare final Drawings and Specifications as prescribed in the Manual of Procedures, and SDE’s Construction Requirements for County and City Public Schools (see Article 1 Definitions for applicability), for Final Plan Submittal.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Final Drawings and Specifications. The Architect shall prepare final Drawings and Specifications as prescribed in the Manual of Procedures and Bulletin 1983 No. 26 for Final Plan Submittal.
Sample 1Sample 2See All (4)
Final Drawings and Specifications. 8.2.1. On the basis of the accepted Design Development documents and the comprehensive update on estimates of probable Total Project Costs and times of completion for the Project, coordinated with the Master Schedule, prepare for incorporation in the Contract Documents final drawings (hereinafter called “Drawings”) and Specifications to show the work to be furnished and performed by Contractor. Drawings and Specifications shall set forth in detail the requirement for construction of all work to be performed by Contractor.
Sample 1Sample 2
Final Drawings and Specifications. A. Construction Documents shall be prepared in accordance with District’s standards. Final technical specifications shall be prepared in conformance with the division format of the Construction Specification Institute. Architect shall cooperate with District in coordinating the Drawings and technical specifications (CSI Divisions 02 and greater) with District’s Divisions 00 Procurement and Contracting Requirements and 01 General Requirements and in jointly revising District’s General Requirements items. Architect shall provide whatever Division 01 General Requirement specifications necessary for the Project and not supplied by District.
Sample 1Sample 2
Final Drawings and Specifications. Those Drawings and Specifications that will be approved by Owner and will become Contract Documents.
Sample 1
Final Drawings and Specifications. After preliminary sketches and estimates have been approved, the Contractor shall proceed with the preparation of reports, drawings, and specifications as required by the Contracting Officer in connection with the Project. Reports, drawings, specifications, and estimates shall be delivered to the Contracting Officer in such sequence and at such times as required by the Contracting Officer. Following review by the Contracting Officer, the Contractor shall make such corrections as are required to obtain the Contracting Officer's approval, and shall submit prints of the final reports, drawings, and specifications.
Sample 1
Final Drawings and Specifications. Within sixty (60) days after the effective date of the Preliminary Drawings, Tenant shall submit to Landlord three (3) sets of fully detailed working drawings covering all aspects of Tenant's Work, prepared, stamped and signed by a California licensed Architect (or licensed California Engineer, as appropriate). Within thirty (30) days after Landlord's receipt thereof, Landlord shall notify Tenant in writing either that the plans are: "Approved as Submitted"; "Approved Subject to Comments"; or "Disapproved," with requirements for changes and/or submittal of supplementary information. Within ten (10) days of receipt after such disapproval, Tenant shall submit to Landlord three (3) sets of corrected and/or supplemented drawings for final approval. Upon approval, Landlord shall return to Tenant one set of drawings, bearing Landlord's written approval; these plans shall be the "Final Drawings" for Tenant's Work. If not approved, the foregoing process shall repeat. Tenant's Work shall be constructed in conformity with the Final Plans, except where Landlord has given prior written approval for modification. Landlord's approval of any plans does not guarantee code compliance, efficiency, safety, or accuracy, for which Tenant is solely responsible.
Sample 1
AutoNDA by SimpleDocs

Related to Final Drawings and Specifications

  • Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.

  • Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.

  • Working Drawings Not later than 15 business days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlord’s receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the TI Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).

  • Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.

  • APPROVAL OF PLANS AND SPECIFICATIONS The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

  • Selection of Architect/Construction Drawings Tenant shall retain the architect/space planner designated by Tenant and reasonably approved by Landlord (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.2. Tenant shall retain the engineering consultants selected by Tenant (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life safety, and sprinkler work in the Premises, which work is not part of the Base Building. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease shall specifically apply to the Construction Drawings.

  • Punchlist Upon completion of the Performance Tests and prior to Substantial Completion of a Subproject, Owner and Contractor shall inspect the Subproject, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion of a Subproject to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion of such Subproject that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion of a Subproject sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of a Subproject after Substantial Completion of the Subproject or the Existing Facility and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion of a Subproject, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.

Time is Money Join Law Insider Premium to draft better contracts faster.