Final Design Drawings Sample Clauses

Final Design Drawings. Tenant and the Architect shall prepare the final design drawings and specifications for Tenant Improvements in the Premises (collectively, the "Final Design Drawings") and shall deliver the same to Landlord for Landlord's approval. The Final Design Drawings shall include a layout and designation of all offices, rooms and other partitioning. Landlord may request clarification or more specific drawings for special use items not included in the Final Design Drawings. Landlord shall advise Tenant within five (5) business days after Landlord's receipt of the Final Design Drawings for the Premises if the same are unsatisfactory or incomplete in any commercially reasonable respect. If Tenant is so advised, Tenant shall promptly cause the Final Design Drawings to be revised to correct any deficiencies or other matters Landlord may reasonably require.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Final Design Drawings. On or before the date set forth in construction schedule attached hereto as Schedule 2 (the "CONSTRUCTION SCHEDULE"), Tenant and the Architect shall prepare the final design drawings and specifications for Tenant Improvements in the Premises (collectively, the "FINAL DESIGN DRAWINGS"), which Final Design Drawings shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein to the extent that such equipment affects the mechanical or electrical design of the Premises, and shall deliver the Final Design Drawings to Landlord for Landlord's approval. Landlord's approval of such drawings shall not be unreasonably withheld or delayed. The Final Design Drawings submitted to Landlord: (i) shall provide for interior improvements only, the design of which shall be reasonably consistent with the space plan attached hereto as Schedule 3; (ii) shall provide for the use of readily available commercial building materials; (iii) shall include mechanical and electrical performance specifications for use as design criteria, and (iv) shall be reasonably sufficient for bidding by design/build subcontractors with a reasonable level of experience in the industry. If the Final Design Drawings delivered to Landlord by Tenant do not meet all of the foregoing criteria, Landlord may proceed to establish a Tenant Delay (as defined in Section 4.1).
Sample 1Sample 2Sample 3See All (4)
Final Design Drawings. Prior to issuance of the site construction plan approval, final design and construction documents shall be submitted to the City for review and approval. Approval will not be granted until the City has been satisfied that the requested design modifications have been made. The design submittal shall include all drawings, specifications and supporting calculations needed to verify that the proposed grading and erosion control align with the concepts approved in the land-use findings and decision and meets the City’s design standards as specified herein. The City will not accept any new infrastructure constructed prior to issuance of the site construction plan approval, or infrastructure not inspected at the site and certified by the City as meeting the required standards.
Sample 1Sample 2Sample 3
Final Design Drawings. (1) Full Size Plan Set • (1) Electronic media in MicroStation Format in accordance with CADD guidelines
Sample 1
Final Design Drawings. The Final Design Drawings will incorporate the comments from the City, and provide additional detail required to finalize the design. The Final Design Drawings will be stamped by a Professional Engineer. Electronic stamping is acceptable. Traffic control drawings assume typical single lane closure approach for pipeline installation, and a 2 stage construction approach with pipeline work in roundabout lanes. No complete roundabout closures are assumed, and therefore no detour plans are included in this scope.
Sample 1
Final Design Drawings. Prior to issuance of the site construction plan approval, final design and construction documents shall be submitted to the City for review and approval. Approval will not be granted until the City has been satisfied that the requested design modifications have been made. The design submittal shall include all drawings, specifications and supporting calculations needed to verify that the proposed grading and erosion control align with the concepts approved in the land-use findings and decision and meets the City’s design standards as specified herein. The City will not accept any new infrastructure constructed prior to issuance of the site construction plan approval, or infrastructure not inspected at the site and certified by the City as meeting the required standards. Final design drawings shall be prepared with a mylar cover sheet for signatures and standard 20lb bright-white paper for the remaining plan sheets with the appropriate professional stamp. Final drawings shall be submitted on ANSI D- 22” X 34”, and electronic PDF half-scale 11” X 17”. Graphical representations of dedicated infrastructure on final design drawings must meet City Drafting Standards (Refer to Section 9). Capital improvement projects will use the standard City title block and drawing format available from the Public Works Department. Land development projects with dedicated infrastructure shall use the City supplied signature block on every drawing submitted. Signature blocks to include, at a minimum, the Public Works Director and any impacted utilities (i.e. Quest, PP&L, DVWD).
Sample 1
Final Design Drawings. Prior to construction approval, final design and construction documents shall be submitted to the City for review and approval. The design submittal shall include all drawings, specifications and supporting calculations needed to verify that the proposed stormwater system aligns with the land use decision concepts and meets the City’s design standards as specified herein. The City will not allow construction of new infrastructure prior to construction plan approval. Also, the City will not take over or accept responsibility for any new infrastructure that has not been inspected, tested, and certified to meet the required standards. Final design drawings shall be prepared with a mylar cover sheet for signatures and standard 20lb bright-white paper for the remaining plan sheets with the appropriate professional stamp. Final drawings shall be submitted on ANSI D- 22”x34”, and electronic PDF half-scale 11”x17”. Graphical representations of dedicated infrastructure on final design drawings must meet City Drafting Standards (Refer to Section 9). Capital improvement projects will use the standard City title block and drawing format available from the Public Works Department. Land development projects with dedicated infrastructure shall use the City supplied signature block on every drawing submitted. Signature blocks to include, at a minimum, the Public Works Director and any impacted utilities (i.e. Quest, PP&L, DVWD).
Sample 1
AutoNDA by SimpleDocs
Final Design Drawings. Final design drawings are complete in details, notes, and all aspects considered at final design. The final design will have fulfilled all design requirements and standards as specified by PUD and Engineering and Capital Projects Department and any other agencies involved in the Project review. Design Professional will incorporate agreed upon City comments from the 100% Submittal. The City will make any final comments of the final design submittal to be incorporated in a revised FINAL design that will be resubmitted by Design Professional as soon as the edits are completed.
Sample 1
Final Design Drawings. The base contract planned for 15 contract drawings. Subsequent, to the development we have identified that the Construction Documents will contain at least 24 contract drawings, an additional 9 sheets. It will take an additional level of effort to generate and edit the additional drawings for the 60%, 90% and 100%/Bid Ready documents. • Additional noteworthy item:
Sample 1

Related to Final Design Drawings

  • Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Working Drawings Not later than 15 business days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlord’s receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the TI Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).

  • Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.

  • Selection of Architect/Construction Drawings Tenant shall retain the architect/space planner designated by Tenant and reasonably approved by Landlord (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.2. Tenant shall retain the engineering consultants selected by Tenant (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life safety, and sprinkler work in the Premises, which work is not part of the Base Building. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease shall specifically apply to the Construction Drawings.

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.

  • Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.

  • Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

  • Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).

Time is Money Join Law Insider Premium to draft better contracts faster.