Extraordinary Measures Sample Clauses

Extraordinary Measures. In the event Owner determines that the performance of the Services has not progressed or reached the level of completion required by the accepted Schedule and does not constitute an Excusable Delay, the Owner shall have the right to order the Engineer to implement corrective measures within ten (10) calendar days of Owner’s written demand, to expedite the progress of Services, including, without limitation, (1) working overtime, (2) supplying additional personnel or Consultants for the Work or other similar measures (hereinafter referred to collectively as Extraordinary Measures). Such Extraordinary Measures shall continue until the progress of the Services complies with the stage of completion required by the Schedule. The Engineer shall not be entitled to an adjustment in compensation in connection with the Extraordinary Measures required by the Owner pursuant to this Section. The Owner may exercise the rights furnished the Owner pursuant to this Section as frequently as the Owner deems necessary to ensure that the Engineer’s performance of Services will comply with the Schedule. If the Engineer fails to implement or commence Extraordinary Measures within ten (10) calendar days of Owner’s written demand, Owner shall have the right to terminate the Engineer for cause.
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
Extraordinary Measures. Measures implemented by Contractor at Owner’s direction to expedite the progress of construction of all or a portion of the Work for a Project, including, without limitation, (i) expediting material shipping, (ii) working additional shifts or overtime, (iii) supplying additional labor, equipment, and facilities and (iv) submitting a recovery schedule for re-sequencing performance of the Work for such Project or other similar measures, as more specifically described in Article GC-2.8 below.
Sample 1
Extraordinary Measures. 8.1.1 In the event the City determines that the performance of the Work, as of a Milestone Date, has not progressed or reached the level of completion required by the Contract Documents, the City shall have the right to order the Design- Builder to take corrective measures necessary to expedite the progress of construction, including, without limitation, (1) working additional shifts or overtime, (2) supplying additional manpower, equipment, and facilities and (3) submitting a Recovery Schedule for re-sequencing performance of the Work or other similar measures (hereinafter referred to collectively as Extraordinary Measures). Such Extraordinary Measures shall continue until the progress of the Work complies with the stage of completion required by the Contract Documents. The City's right to require Extraordinary Measures is solely for the purpose of ensuring the Design-Builder's compliance with the Project Schedule.
Sample 1
Extraordinary Measures. 3.6.1 If the progress of the Work falls behind that required by the Milestone Schedule (as revised to reflect any Excused Delay) in any material way, if requested by Owner, Contractor shall work additional shifts or overtime, supply additional manpower or equipment, or take other similar measures, as specified by Owner, and shall continue such measures until the progress of the Work has reached the stage then required by the Milestone Schedule (as revised to reflect any Excused Delay). Contractor shall not be entitled to an increase in the Contract Sum on account of such measures.
Sample 1
Extraordinary Measures. In the event Owner determines that the performance of the Work, as of a Milestone Date, has not progressed or reached the level of completion required by the Contract Documents, Owner shall have the right to order Contractor to take corrective measures necessary to expedite the progress of construction, including (a) working additional shifts or overtime, (b) supplying additional manpower, equipment and facilities, and (c) other similar measures (collectively, “Extraordinary Measures”). Such Extraordinary Measures shall continue until the progress of the Work complies with the stage of completion required by the Contract Documents. Owner’s right to require Extraordinary Measures is solely for the purpose of ensuring Contractor’s compliance with the Milestone Schedule. Contractor shall not be entitled to an adjustment of the Contract Sum in connection with Extraordinary Measures required by Owner under or pursuant to this Paragraph 2.5, unless such Extraordinary Measures are ordered by Owner as a result of a delay for which Contractor is entitled to an extension of the Contract Time under Paragraph 5.6. Owner may exercise the rights furnished Owner under or pursuant to this Paragraph 2.5 as frequently as Owner deems necessary to ensure that Contractor’s performance of the Work will comply with any Milestone Dates or completion deadlines set forth in the Contract Documents.
Sample 1
Extraordinary Measures. If Owner determines that the performance of the Services under a Service Order has not progressed or reached the level of completion required by the accepted Schedule for the Project to which such Service Order pertains, then Owner shall have the right to order Architect to implement corrective measures within ten
Sample 1

Related to Extraordinary Measures

  • Emergency Measures Additional measures and/or other special requirements necessary during periods of critical fire-weather conditions shall be included in the fire prevention and presuppression plan.

  • Disciplinary Measures 19.01 Any disciplinary measure must be the subject of a written notice addressed to the employee concerned and stating the reasons for the measure. Such notice must be sent simultaneously to the Union. Only those disciplinary measures of which the employee and the Union have been informed in writing can be used as evidence in arbitration and can appear in the employee's employment file.

  • Interim Measures 6.1 The Parties acknowledge that the British Columbia Claims Task Force made the following recommendation concerning interim measures:

  • Other Measures 1. A Contracting Party may not require that an enterprise of that Contracting Party that is an investment under this Agreement appoint to senior management positions individuals of any particular nationality.

  • Bilateral Safeguard Measures 1. Where, as a result of the reduction or elimination of a customs duty under this Agreement, any product originating in a Party is being imported into the territory of another Party in such increased quantities, in absolute terms or relative to domestic production, and under such conditions as to constitute a substantial cause of serious injury or threat thereof to the domestic industry of like or directly competitive products in the territory of the importing Party, the importing Party may take bilateral safeguard measures to the minimum extent necessary to remedy or prevent the injury, subject to the provisions of paragraphs 2 to 10.

  • Measures SAP protects its assets and facilities using the appropriate means based on the SAP Security Policy • In general, buildings are secured through access control systems (e.g., smart card access system). • As a minimum requirement, the outermost entrance points of the building must be fitted with a certified key system including modern, active key management. • Depending on the security classification, buildings, individual areas and surrounding premises may be further protected by additional measures. These include specific access profiles, video surveillance, intruder alarm systems and biometric access control systems. • Access rights are granted to authorized persons on an individual basis according to the System and Data Access Control measures (see Section 1.2 and 1.3 below). This also applies to visitor access. Guests and visitors to SAP buildings must register their names at reception and must be accompanied by authorized SAP personnel. • SAP employees and external personnel must wear their ID cards at all SAP locations.

Time is Money Join Law Insider Premium to draft better contracts faster.