Estimated Cost of Services Sample Clauses

Estimated Cost of Services. A cost estimate for election expenses is attached hereto and made a part of this contract as Exhibit “C” or Exhibit “C-1”, whichever is applicable. The parties agree that these are an estimate only and that the CITY is obligated to pay their respective portion of the actual expenses of the election as set forth herein. The Contracting Officer agrees to advise the CITY if it appears that the actual expenses incurred by the Contracting Officer will exceed by 20% or more the estimated expenses to be paid initially by the Contracting Officer and reimbursed jointly by the CITY.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Estimated Cost of Services a. A cost estimate for election expenses is set forth in Exhibit “F”, attached hereto and made part of this contract. The Contracting Officer agrees to advise the LPS if it becomes apparent that the actual expenses incurred by the Contracting Officer will exceed by 20% or more the estimated expenses as set forth in Exhibit “F”.
Sample 1
Estimated Cost of Services. SEE EXHIBIT “A” The Political Subdivision(s) agree that Exhibit “A” is an estimate only and the Political Subdivision(s) are obligated to pay the actual expenses of the election.
Sample 1

Related to Estimated Cost of Services

  • Cost of Services Political Subdivision shall share some expenses for the above services, supplies and equipment. Additional elections may lower costs for each entity, and election cancellations may raise costs for each entity. It is understood that other political entities may wish to participate in the use of the County’s electronic voting equipment and polling locations, and it is agreed that Contracting Officer may enter into other contracts with entities for those purposes on terms and conditions generally similar to those set forth in this Agreement. Only the actual expenses directly attributable to this Agreement and any prorated shared expenses may be charged to Political Subdivision, plus a 10% administrative fee.

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • Cost of Additional Review The Design Professional shall be responsible for an initial and one subsequent review of the Submittal. Where the subsequent Submittal is not accepted due to noncompliance with the Contract Documents, the Contractor shall be responsible for payment for the additional time required by the Design Professional to complete the Submittal review.

  • Payment of Service Fees Customer will pay the Service Fees for Services ordered by Customer, and all other amounts due under the Agreement, pursuant to the terms of this Section 5.

  • Commencement of Services The Consultant shall begin carrying out the Services from the Effective Date or from such other Date specified in the SC.

  • Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.

  • Supply of Services 3.1 In consideration of the amounts due under this Agreement, the Supplier shall, from the date set out in the Purchase Order or Award Letter, provide the Services to the Customer for the Term, in accordance with the terms and conditions with this Agreement.

  • Period of Services Unless otherwise stated herein, the Consultant will begin work after receipt of a properly executed copy of this Agreement. This Agreement assumes conditions permitting continuous and orderly progress through completion of the services. Times for performance shall be extended as necessary for delays or suspensions due to circumstances that the Consultant does not control. If such delay or suspension extends for more than six months, Consultant’s compensation shall be renegotiated.

  • Additional Services Compensation Additional Services Compensation shall be the fees determined in accordance with Article 7 to be paid by the Owner to the Professional Consultant in connection with the performance of Additional Services.

  • Payment of Services 1. For courses taught at a High School facility utilizing High School teachers who are qualified by the DCCCD College using Southern Association of Colleges and Schools Commission on Colleges (SACSCOC) standards to teach college level courses, DCCCD shall pay as follows:

Time is Money Join Law Insider Premium to draft better contracts faster.