Construction Contracts Lessee has entered into contracts with the Contractors or separate contracts with materialmen and laborers providing for the construction of the Improvements. Lessee will cause the Contractors to promptly furnish Lessor with the complete list of all Sub-contractors or entities as and when under contract, which Contractors propose to engage to furnish labor and/or materials in constructing the Improvements (such list containing the names, addresses, and amounts of such sub-contracts as written in excess individually of $5,000, and prior to disbursement of funds to or for the benefit of such Subcontractors, affidavits of authorized signatory and other documents commercially reasonably required by Title to insure that the Leased Premises remain lien free) and will from time to time furnish Lessor or Title with true copies of all Contracts entered into by Lessee and with the terms of all verbal agreements therefor, if any, and as to subcontractors, letters signed by sub-contractors whose contracts are in excess of $5,000 setting forth the present amount of their contract and the amounts remaining to be paid under that contract, if the same information is not stated on a lien waiver reflecting the most currently requested payment to such subcontractor.
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
Construction Contract On each Borrowing Date, the Borrower shall have certified that all conditions and requirements under the Construction Contract required to be satisfied on such Borrowing Date, including in connection with the respective payment installments to be made to the Yard on such Borrowing Date, shall have been satisfied (including, but not limited to, the Borrower’s payment to the Yard of the portion of the payment installment on the Vessel that is not being financed with proceeds of the Loans), other than those that are not materially adverse to the Lenders, it being understood that any litigation between the Yard and the Parent and/or Borrower shall be deemed to be materially adverse to the Lenders.
Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.
General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)
Project Contracts (i) all existing Project Contracts are or will be in full force and effect at the time of the first drawdown under this Agreement (except for the EPC Contract, which will be in full force and effect once the down payment under the EPC Contract has been made), (ii) no other material Project Contracts have been concluded, which have not been disclosed to the Agent, (iii) the Borrower has no notice of any material breaches by any contracting party under the Project Contracts, and (iv) with regard to Project Contracts, which will not be available before the day on which this representation and warranty is made or repeated, the Borrower assumes that these are produced as soon as and to the extent that they may become necessary for the Project;
General Construction Principles Words in any gender are deemed to include the other genders. The singular is deemed to include the plural and vice versa. The headings and underlined paragraph titles are for guidance only and have no significance in the interpretation of this Agreement.
