Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors Sample Clauses

Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors. (a) The Issuer hereby authorizes the Company, as agent of the Issuer or in its own behalf, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require all manufacturers, fabricators, vendors, contractors and subcontractors and suppliers to complete their contracts relating to the Project diligently in accordance with the terms of such contracts, including, without limitation, the correction of any defects. The Issuer agrees that the Company may, from time to time, in its own name, or in the name of the Issuer, take such action as the Company may elect in its sole discretion against such manufacturers, fabricators, vendors, contractors and subcontractors and suppliers, and their sureties, to insure the proper acquisition, construction and equipping of the Project.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors. (a) The Issuer hereby authorizes the Company at the expense of the Company, as agent of the Issuer or in its own behalf, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require all manufacturers, fabricators, vendors, contractors and subcontractors and suppliers to complete their contracts relating to the Project diligently in accordance with the terms of such contracts, including, without limitation, the correction of any defects. The Issuer agrees that the Company may, from time to time, in its own name, or in the name of the Issuer (provided the Issuer is indemnified to its satisfaction), take such action as the Company may elect in its sole discretion against such manufacturers, fabricators, vendors, contractors and subcontractors and suppliers, and their sureties, to insure the proper acquisition, construction and equipping of the Project.
Sample 1
Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors. The Issuer hereby authorizes the Company, as agent of the Issuer or in its own behalf, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require all manufacturers, fabricators, vendors, contractors and subcontractors and suppliers to complete their contracts relating to the Project diligently in accordance with the terms of such contracts, including, without limitation, the correction of any defects. The Issuer agrees that the Company may, from time to time, in its own name, or in the name of the Issuer, take such action as the Company may elect in its sole discretion against such manufacturers, fabricators, vendors, contractors and subcontractors and suppliers, and their sureties, to insure the proper acquisition, construction and equipping of the Project. The Issuer hereby authorizes the Company, as agent of the Issuer or on its own behalf, and at the sole expense of the Company, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require any contractors, manufacturers and dealers that have provided labor or materials (including building fixtures) for the Project to fulfill their warranties and contractual responsibilities diligently in accordance with the terms of any purchase or installation contracts, including, without limitation, the correction of any defective parts or workmanship. The Issuer agrees that the Company may, from time to time, take such action as the Company may elect in its sole discretion to insure the conformity of the Project to the specifications therefor.
Sample 1

Related to Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors

  • No Waiver of Provisional Remedies, Self-Help and Foreclosure The arbitration requirement does not limit the right of any party to (i) foreclose against real or personal property collateral; (ii) exercise self-help remedies relating to collateral or proceeds of collateral such as setoff or repossession; or (iii) obtain provisional or ancillary remedies such as replevin, injunctive relief, attachment or the appointment of a receiver, before during or after the pendency of any arbitration proceeding. This exclusion does not constitute a waiver of the right or obligation of any party to submit any dispute to arbitration or reference hereunder, including those arising from the exercise of the actions detailed in sections (i), (ii) and (iii) of this paragraph.

  • Rights and Remedies of the Collateral Agent (a) In addition to the rights and remedies specified in Section 4.4 hereof or otherwise available at law or in equity, after an event of default hereunder, the Collateral Agent shall have all of the rights and remedies with respect to the Collateral of a secured party under the Uniform Commercial Code (or any successor thereto) as in effect in the State of New York from time to time (the "Code") (whether or not the Code is in effect in the jurisdiction where the rights and remedies are asserted) and the TRADES Regulations and such additional rights and remedies to which a secured party is entitled under the laws in effect in any jurisdiction where any rights and remedies hereunder may be asserted. Wherever reference is made in this Agreement to any section of the Code, such reference shall be deemed to include a reference to any provision of the Code which is a successor to, or amendment of, such section. Without limiting the generality of the foregoing, such remedies may include, to the extent permitted by applicable law, (i) retention of the Pledged Debt Securities or other Collateral in full satisfaction of the Holders' obligations under the Purchase Contracts or (ii) sale of the Pledged Debt Securities or other Collateral in one or more public or private sales and application of the proceeds in full satisfaction of the Holders' obligations under the Purchase Contracts.

  • Reliance on Attorneys and Agents The Rights Agent may execute and exercise any of the rights or powers hereby vested in it or perform any duty hereunder either itself or by or through its attorneys or agents, and the Rights Agent shall not be answerable or accountable for any act, omission, default, neglect or misconduct of any such attorneys or agents or for any loss to the Company resulting from any such act, omission, default, neglect or misconduct, provided that reasonable care was exercised in the selection and continued employment thereof.

  • Waiver of Immunities To the extent that the Company or any of its properties, assets or revenues may have or may hereafter become entitled to, or have attributed to it, any right of immunity, on the grounds of sovereignty or otherwise, from any legal action, suit or proceeding, from the giving of any relief in any respect thereof, from setoff or counterclaim, from the jurisdiction of any court, from service of process, from attachment upon or prior to judgment, from attachment in aid of execution or judgment, or from execution of judgment, or other legal process or proceeding for the giving of any relief or for the enforcement of any judgment, in any jurisdiction in which proceedings may at any time be commenced, with respect to its obligations, liabilities or any other matter under or arising out of or in connection with the Shares or Deposited Securities, the American Depositary Shares, the Receipts or this Agreement, the Company, to the fullest extent permitted by law, hereby irrevocably and unconditionally waives, and agrees not to plead or claim, any such immunity and consents to such relief and enforcement.

  • Conditions Precedent and Secured Party’s Rights and Remedies The following Termination Events will be a “Specified Condition” for the party specified (that party being the Affected Party if the Termination Event occurs with respect to that party): With respect to Party A: any Additional Termination Event with respect to which Party A is the sole Affected Party. With respect to Party B: None.

  • Waivers and Amendments; Non-Contractual Remedies; Preservation of Remedies This Guaranty may be amended, superseded, canceled, renewed or extended, and the terms hereof may be waived, only by a written instrument signed by the parties or, in the case of a waiver, by the party waiving compliance. No delay on the part of any party on exercising any right, power or privilege hereunder shall operate as a waiver thereof, nor shall any waiver on the part of any party of any right, power or privilege, nor any single or partial exercise of any such right, power or privilege, preclude any further exercise thereof or the exercise of any other such right, power or privilege. The rights and remedies herein provided are cumulative and are not exclusive of any rights or remedies that any party may otherwise have at law or in equity.

  • Enforcement of Agreements After being translated into Spanish by an official translator, this Agreement, the Indenture and the Securities, upon the due execution, issuance and delivery thereof, will be in proper legal form under the laws of the Republic for the enforcement thereof in the Republic against the Republic.

  • Rights and Remedies Not Waived No act, omission or delay by the Collateral Agent shall constitute a waiver of the Collateral Agent's rights and remedies hereunder or otherwise. No single or partial waiver by the Collateral Agent of any default hereunder or right or remedy that it may have shall operate as a waiver of any other default, right or remedy or of the same default, right or remedy on a future occasion.

  • Tenant’s Remedies/Limitation of Liability Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.

Time is Money Join Law Insider Premium to draft better contracts faster.