Energy Delivery and Ownership
Energy Delivery and Ownership Sample Clauses
Related to Energy Delivery and Ownership
DELIVERY AND TITLE 3.1 The delivery dates and addresses are those in the Order. Time shall be of the essence in respect of the Supplier/Service Provider’s obligations under the Order.
Title and Ownership Warranty Contractor warrants, represents and conveys (i) full ownership, clear title free of all liens, or (ii) the right to transfer or deliver perpetual license rights to any Products transferred to Authorized User under this Contract. Contractor shall be solely liable for any costs of acquisition associated therewith. Contractor fully indemnifies the Authorized User for any loss, damages or actions arising from a breach of said warranty without limitation.
Delivery and Risk of Loss Unless otherwise provided for in advance, all shipments will be made F.O.B. Seller's facility, and upon Seller's delivery of a shipment to the carrier, Buyer shall assume the risk of any loss or damage to the shipment thereafter. Delivery and/or completion dates furnished by Seller represent the best estimates of the time required to make shipment or complete services, and Seller does not guarantee delivery or completion by a particular date unless otherwise stated herein or in any schedule or addendum attached hereto. If a delivery date for products is guaranteed herein, (a) Seller’s unexcused delay in delivering one installment to the carrier at Seller’s facility shall permit Buyer to cancel only that installment, and acceptance by Buyer or the act of taking possession of products by the carrier shall constitute a bar to any claim of late delivery with respect to such products and (b) Buyer shall not be excused from performance if for any reason, the carrier does not pick up products on the date specified for shipping, and Seller may dispose of any products which the carrier does not pick-up within five (5) days of the date agreed for delivery to the carrier at Seller’s facility if Buyer refuses acceptance based on such delay, in which case Seller may cancel the order without notice to Buyer and Buyer shall be responsible for a 25% restocking fee as to the products ordered. In any such event, Seller shall have no duty to mitigate its damages. Seller may deliver any products subject to an order to the carrier at its facility in part and in such event, Buyer shall be responsible for payment for that part of the order received by the carrier, and Seller shall only be responsible for that portion of an order which Seller is required to but does not deliver. Unless otherwise required by a contract of Buyer with a customer of Buyer with respect only to products ordered by such customer, Title shall not pass with respect to any products ordered until Buyer makes payment in full thereof. In the alternative, Seller reserves a purchase money security interest in the products sold as well as any other products or property forwarded to Seller by Buyer for servicing or evaluation until full payment has been received. Buyer agrees to execute any document appropriate or necessary to perfect Seller's security interest or to acknowledge that title remains with Seller. In the alternative, Seller may file this order as a financing statement and/or chattel mortgage. Buyer agrees that, upon its failure to pay any invoice when due, Seller may immediately foreclose upon and sell, in a manner determined by Seller, any products or property owned by or provided by Buyer to Seller, regardless of whether such products or property are the subject of the unpaid invoice, in order to allow Seller to recover all amounts, including but not limited to interest and penalties, owed by Buyer to Seller.
Risk and Ownership C14.1 Subject to clause C13 above, risk in the Goods shall, without prejudice to any other rights or remedies of the Authority (including the Authority’s rights and remedies under clause C16 below) pass to the Authority when delivery is completed to the Authority’s reasonable satisfaction.
Delivery and Documents 13.1 Subject to GCC Sub-Clause 33.1, the delivery of the Goods and completion of the Related Services shall be in accordance with the List of Goods and Delivery Schedule specified in the Supply Requirements. The details of shipping and other documents to be furnished by the Supplier are specified in the SCC.
Delivery and Risk 7.1 Unless otherwise stated in the Order, the price quoted includes delivery to the address specified in the Order.
Title and Ownership Contractor warrants and represents that it has (i) full ownership, clear title free of all liens, or (ii) the right to transfer or deliver specified license rights to any Products acquired by Authorized User under this Contract. Contractor shall be solely liable for any costs of acquisition associated therewith. Contractor shall indemnify Authorized Users and hold Authorized Users harmless from any damages and liabilities (including reasonable attorneys’ fees and costs) awarded by a court of competent jurisdiction arising from any breach of Contractor’s warranties as set forth herein.
License and Ownership 1.1 Pursuant to the terms and conditions specified in this Agreement, Starfish hereby grants to Customer, and Customer hereby accepts from Starfish, a nontransferable, nonexclusive right and license to use the software (the “Solution”) identified in the Ordering Document during the Term (as defined in Section 2.1) for Customer’s own internal business purposes.
Transfer and Ownership of Warrants (1) The Warrants may only be transferred on the register kept by the Warrant Agent at the Warrant Agency by the holder or its legal representatives or its attorney duly appointed by an instrument in writing in form and execution satisfactory to the Warrant Agent only upon (a) in the case of a Warrant Certificate, surrendering to the Warrant Agent at the Warrant Agency the Warrant Certificates representing the Warrants to be transferred together with a duly executed transfer form as set forth in Schedule “A” and (b) in the case of Book Entry Warrants, in accordance with procedures prescribed by the Depository under the book entry registration system, and (c) upon compliance with:
RESERVATION OF RIGHTS AND OWNERSHIP PFU or its suppliers own the title, copyright, and other intellectual property rights in the Software. The Software is protected by copyright and other intellectual property laws and treaties. Except as expressly stated herein, this XXXX does not grant you any intellectual property rights in the Software. All rights not expressly granted are reserved by PFU and its suppliers.
