Notice of Claim Reduction of Policy Limits The Consulting Engineer/Architect, upon receipt of notice of any claim in connection with the Contract, shall promptly notify the City, providing full details thereof, including an estimate of the amount of loss or liability. The Consulting Engineer/Architect shall monitor and promptly notify the City of any reduction in limits of protection afforded under any policy listed in the Certificate (or otherwise required by the contract) if the Consulting Engineer/Architect’s limits of protection shall have been impaired or reduced to such extent that the limits fall below the minimum amounts required herein. The Consulting Engineer/Architect shall promptly reinstate the original limits of liability required hereunder and shall furnish evidence thereof to the City.
Waiver of Claim for Attorney’s Fees The defendant waives all of his claims under the Hyde Amendment, 18 U.S.C. § 3006A, for attorney’s fees and other litigation expenses arising out of the investigation or prosecution of this matter.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
LIMITATION OF COUNTY LIABILITY FOR DISALLOWANCES 10.1. Notwithstanding any other provision of the Agreement, COUNTY will be held harmless by CONTRACTOR from any Federal or State audit disallowance and interest resulting from payments made to CONTRACTOR pursuant to this Agreement, less the amounts already submitted to the State for the disallowed claim.
Indemnification Procedure Any person obligated to provide indemnification under this Article VIII ("Indemnifying Party" for the purpose of this Section 8.3) will not be liable under the indemnification provisions of this Article VIII with respect to any claim made against a party entitled to indemnification under this Article VIII ("Indemnified Party" for the purpose of this Section 8.3) unless such Indemnified Party will have notified the Indemnifying Party in writing within a reasonable time after the summons or other first legal process giving information of the nature of the claim will have been served upon such Indemnified Party (or after such party will have received notice of such service on any designated agent), but failure to notify the Indemnifying Party of any such claim will not relieve the Indemnifying Party from any liability which it may have to the Indemnified Party against whom such action is brought otherwise than on account of the indemnification provision of this Article VIII, except to the extent that the failure to notify results in the failure of actual notice to the Indemnifying Party and such Indemnifying Party is damaged solely as a result of failure to give such notice. In case any such action is brought against the Indemnified Party, the Indemnifying Party will be entitled to participate, at its own expense, in the defense thereof. The Indemnifying Party also will be entitled to assume the defense thereof, with counsel satisfactory to the party named in the action. After notice from the Indemnifying Party to the Indemnified Party of the Indemnifying Party's election to assume the defense thereof, the Indemnified Party will bear the fees and expenses of any additional counsel retained by it, and the Indemnifying Party will not be liable to such party under this Agreement for any legal or other expenses subsequently incurred by such party independently in connection with the defense thereof other than reasonable costs of investigation, unless: (a) the Indemnifying Party and the Indemnified Party will have mutually agreed to the retention of such counsel; or (b) the named parties to any such proceeding (including any impleaded parties) include both the Indemnifying Party and the Indemnified Party and representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them. The Indemnifying Party will not be liable for any settlement of any proceeding effected without its written consent but if settled with such consent or if there is a final judgment for the plaintiff, the Indemnifying Party agrees to indemnify the Indemnified Party from and against any loss or liability by reason of such settlement or judgment. A successor by law of the parties to this Agreement will be entitled to the benefits of the indemnification contained in this Article VIII. The indemnification provisions contained in this Article VIII will survive any termination of this Agreement.
