Dry Utilities Sample Clauses

Dry Utilities. Electricity, natural gas, and telephone service will be installed by local utility companies. The installations may not be completed at the time of a Closing, and are not part of the Finish Lot Improvements; provided, however, that: (i) with respect to electric distribution lines and street lights, Seller will have signed an agreement with the electric utility service provider and paid all costs and fees for the installation of electric distribution lines and facilities to serve the Lots, and all sleeves necessary for electric, gas, telephone and/or cable television service to the Lots will be installed; (ii) with respect to gas distribution lines, Seller will have signed an agreement with the gas utility service provider and paid all costs and fees for the installation of gas distribution lines and facilities to serve the Lots. Seller will take commercially reasonable efforts to assist Purchaser in coordinating with these utility companies to provide final electric, gas, telephone and cable television service to the residences on the Lots, however, Purchaser must activate such services through an end user contract. Purchaser acknowledges that in some cases the telephone and cable companies may not have pulled the main line through the conduit if no closings of residences have occurred. Notwithstanding the foregoing, if dry utilities have not been installed upon Substantial Completion of the Finished Lot Improvements, Seller shall be obligated to have contracted for same and paid all costs and fees payable for such installation. Unless Seller has contracted for such installation and paid such costs before the Effective Date, Seller will give Purchaser notice when such contracts have been entered and such costs paid. With respect to any Finished Lot Improvements that are required by the subdivision improvement agreement applicable to the Lots but which are not addressed as part of the Finished Lot Improvements, and any other improvements which are not required for the issuance of building permits but which are required by the Authorities so that dwellings and other improvements constructed by Purchaser on the Lots are eligible for the issuance of certificates of occupancy for homes, Seller shall complete such other improvements, to the extent required by the County, so as not to delay the issuance of certificates of occupancy for residences constructed by Purchaser on the Lots.
Sample 1Sample 2See All (8)
AutoNDA by SimpleDocs
Dry Utilities. Design and construct ducts, vaults, junction boxes and related substructure elements for Electrical, Telephone (including fiber optics), and main line Gas systems. Line and ducts will stubbed to the right of way line to provide service to each lot. Such work shall be coordinated with utility companies. (See attached Gas Lines.)
Sample 1Sample 2Sample 3See All (4)
Dry Utilities. Developer shall construct dry utilities serving the Project as set forth in the Infrastructure Financing Plan.
Sample 1Sample 2Sample 3See All (4)
Dry Utilities. Developer shall construct the following improvements: (1) a gas main extending from Ferrari Ranch Road to the Project’s eastern entry road; and (2) excluding the existing 69 kV electric utility lines, the undergrounding of the existing public utilities along the Project frontage as set forth in Tentative Map condition of approval 124.
Sample 1Sample 2
Dry Utilities. Subject to all of the provisions of this Agreement, the County agrees to acquire from the Company and/or reimburse the Company for those Project Facilities and Privately-Owned Dry Utilities listed in Exhibit A which are constructed by the Company and tendered for acquisition and/or reimbursement in accordance with the provisions of this Agreement. The Company agrees that any Project Facility being constructed by, or under the direction of, the Company shall be constructed in substantial compliance with the Director-approved Plans. The Company agrees that any Project Facility and Privately-Owned Dry Utility being constructed by, or under the direction of, the Company shall be constructed in compliance with the requirements of Government Code Section 53313.5, which requires those improvements for which construction was not complete before the resolution of formation to establish the District was adopted, as determined by the Board of Supervisors, to be constructed as if such improvements had been constructed under the direction and supervision, or under the authority, of the County. In partial satisfaction of the requirements of Section 53313.5, with respect to any Project Facilities (excluding those Project Facilities listed under Exhibit A Part V.1.) for which construction was not complete before the resolution of formation to establish the District was adopted, as determined by the Board of Supervisors, the Company shall be required to secure the faithful performance of construction and completion of construction of such Project Facilities, by appropriate contractor’s bonds as required by the California Public Contracts Code. In addition, in partial satisfaction of the requirements of Section 53313.5, with respect to any Project Facilities and the Privately-Owned Dry Utilities for which construction was not complete before the resolution of formation to establish the District was adopted, as determined by the Board of Supervisors, the Company shall require its contractor or contractors to pay the prevailing rate of per diem wages for work of a similar character in the locality of the District and not less than the general prevailing rate of per diem wages for holiday and overtime work, as provided in Section 1771 et seq. of the California Labor Code, to all workers employed by each such contractor in the construction of such Project Facilities and Privately-Owned Dry Utilities. As to each Project Facility and Privately-Owned Dry Utility for which construc...
Sample 1
Dry Utilities. The Owner shall be responsible for coordinating the installation and activation of dry utilities and phone lines to the Project. The Construction Manager will assist in that coordination as requested by the Owner, and will provide in the Construction Schedule the date by which the dry utilities and phone lines need to be installed and activated so as not to delay progress of the Work. If such activation is delayed beyond the date provided for in the Construction Schedule, and if and to the extent such delay impacts the critical path of the then-current Construction Schedule, the Construction Manager shall be entitled to an extension of the Contract Time equal to the period of such critical path delay and the Contract Sum shall be adjusted for the additional General Conditions Costs for such delay by Change Order.
Sample 1
Dry Utilities 
Sample 1
AutoNDA by SimpleDocs

Related to Dry Utilities

  • Services and Utilities Landlord shall furnish all normal services and utilities such as elevator service, lighting replacement for building standard lights, restroom supplies, window washing, janitorial services, heating, ventilation and air conditioning (“HVAC”) maintenance, landscape maintenance, parking lot sweeping, pest control services, and fire alarm monitoring (if installed and required) in a manner that such services are customarily furnished to comparable office buildings in the area. Landlord shall also provide water, sewer, electric, gas and trash removal services to the building as required. Provided that Tenant is not in default hereunder, Landlord agrees to furnish to the Premises at all times , electricity for normal desk top office equipment, .normal copying equipment, technical equipment, and “HVAC” as is reasonably required for the comfortable use and occupancy of the Premises. The normally recognized business hours for the Building are as follows: 7:00 am to 6:00 pm Monday through Friday (except Holidays), and 8:00 am to 1:00 p.m. on Saturdays. If Tenant desires HVAC and/or electricity at any other time, Tenant may override the HVAC and/or electricity system for additional heating, cooling or electricity outside of the normal business hours. Such additional HVAC and/or electricity usage shall be electronically monitored, and Tenant shall pay Landlord’s direct charges therefore on demand. Landlord shall also maintain and keep lighted the common stairs, common entries and restrooms in the Building. Landlord shall not be in default hereunder or be liable for any damages directly or indirectly resulting from, nor shall the Rent be abated by reason of (i) the installation, use or interruption of use of any equipment in connection with the furnishing of any of the foregoing services, (ii) failure to furnish or delay in furnishing any such services where such failure or delay is caused by accident or any condition or event beyond the reasonable control of Landlord, or by the making of necessary repairs or improvements to the Premises, Building or Project, or (iii) the limitation, curtailment or rationing of, or restrictions on, use of water, electricity, gas or any other form of energy serving the Premises, Building or Project, which has been imposed upon the Landlord. Landlord shall not be liable except where Landlord is found to be grossly negligent for a loss of or injury to property or business, however occurring, through or in connection with or incidental to failure to furnish any such services. If Tenant uses heat generating machines or equipment in the Premises which affect the temperature otherwise maintained by the HVAC system, Landlord reserves the right to install supplementary air conditioning units in the Premises and the cost thereof, including the cost of installation, operation and maintenance thereof, shall be paid by Tenant to Landlord upon demand by Landlord. Should Tenant consume water or electric current in excess of that usually furnished or supplied for the use of premises as general office space Landlord may have installed a water meter or electrical current meter in the Premises to measure the amount of water or electric current consumed. The cost of any such meter and its installation, maintenance and repair shall be paid for by the Tenant and Tenant agrees to pay to Landlord promptly upon demand for all such water and electric current consumed as shown by said meters, at the rates charged for such services by the local public utility. If a separate meter is not installed, the excess cost for such water and electric current shall be established by an estimate made by a utility company or an electrical engineer hired jointly by Landlord and Tenant and at Tenant’s expense. Nothing contained in this Section shall restrict Landlord’s right to require at any time separate metering of utilities furnished to the Premises. In the event utilities are separately metered, Tenant shall pay promptly upon demand for all utilities consumed at utility rates charged by the local public utility plus any additional expense incurred by Landlord in keeping account of the utilities so consumed. Tenant shall be responsible for the maintenance and repair of any such meters at its sole cost.

  • Availability of Utilities All utility services necessary for the construction of the Improvements will be available prior to the commencement of construction, and all utility services necessary for the proper operation of the Improvements for their intended purposes are available at the Leased Premises or will be available at the Leased Premises prior to the Final Disbursement Date, at commercially comparable utility rates and hook-up charges for the vicinity, including water supply, storm and sanitary sewer facilities, gas, electricity and telephone facilities. Lessee shall furnish evidence of such availability of utilities from time to time at Lessor's request.

  • Taxes and Utilities The Landlord will pay for all charges assessed against the Premises during the term of this Lease for real estate taxes, water, heat, and electricity. In the event that the Tenant installs any equipment resulting in a significant increase in the demand for power or cooling, the Tenant shall pay the additional cost of such power and cooling as an additional monthly rental payment to be determined by the Landlord. The Landlord has made arrangements for a uniform rate structure for each tenant on the Property with a communications and data provider (the word “communications” and the word “data” as used in this Lease shall include any and all telephonic or electronic transmissions from one place to another of written materials or oral communications and/or transmission of data). The Tenant shall be responsible for paying directly to the service provider, when due, such phone and data line installation charges and monthly service charges as well as the actual costs of all calls. In the event that the Tenant elects to move from the Premises to other premises within the Property, the Tenant acknowledges that it will be liable for the foregoing installation charge for each and every such move.

  • GOVERNMENT ENERGY OR UTILITY CONTROLS In the event of imposition of federal, state or local government controls, rules, regulations, or restrictions on the use or consumption of energy or other utilities during the Term, both Landlord and Tenant shall be bound thereby. In the event of a difference in interpretation by Landlord and Tenant of any such controls, the interpretation of Landlord shall prevail, and Landlord shall have the right to enforce compliance therewith, including the right of entry into the Premises to effect compliance.

  • Utilities The Landlord shall provide the following utilities and services to the Tenant: _ _. Any other utilities or services not mentioned will be the responsibility of the Tenant.

  • Electric If Customer has selected an Electricity Fixed Rate on the Application, Customer’s Price will be based on the Fixed Rate(s) which includes Local and State taxes, Gross Receipts Tax (GRT), PJM Adjustment (defined below) charges and adjustments and Utility applied charges and/or fees related to generation, plus the Administration Charge, which includes, Electricity Balancing Amount and third party utility and billing charges. Customer understands and agrees that included in the Administration Charge is the cost of the Energy Balancing Amount (defined below). Customer understands that in order for RITERATE ENERGY to be able to supply Energy to its existing and prospective customers, RITERATE ENERGY enters into supply arrangements to meet the forecasted consumption of its various groups of customers. These forecasts are based on historical data, load shapes and/or estimates. To the extent that actual pooled consumption of RITERATE ENERGY’s Energy customers varies from supply arrangements and/or Customer’s Utility delivery requirements, RITERATE ENERGY incurs a cost in balancing and settling its supply arrangements with such pooled consumption. To ensure a fixed all-inclusive Rate, RITERATE ENERGY has included in the Administration charge, the Energy Balancing Amount, to balance and settle the variance between pooled consumption and supply arrangements (the “Energy Balancing Amount”). In respect of Electricity, Customer understands that there are certain estimated pass through costs, made up of charges to RITERATE ENERGY by the PJM Interconnection (“PJM”) and/or Customer’s Utility, including but not limited to ancillary service charges, the cost of unaccounted for electricity, capacity charges and any replacement or recharacterization of these charges. In this regard, the “PJM Adjustment”, is included in the Fixed Price Rate. Customer acknowledges and agrees that by entering into this Agreement, Customer will not be eligible to receive any net metering credits and other incentives to which Customer would otherwise be entitled. Further, included in the Rate are the amounts charged or billed to RITERATE ENERGY or Customer by Customer’s Utility, the PUC or any other regulatory or government entity, including any taxes, delivery, regulated transmission, regulated distribution, pipeline, compressor fuel, uplift, congestion, locational marginal pricing, invoice market participant, service, billing, or similar or related changes and any, deposits, interest or late payment fees or other amounts in connection with the supply and delivery of Energy to the Premises (collectively, “Regulatory Charges”). Customer agrees to pay the monthly Administration charge for Energy supply (the “Administration” charge).

  • TAXES, ASSESSMENTS AND UTILITIES (A) Lessee shall be liable and agrees to pay the charges for all public utility services rendered or furnished to the Leased Premises, including heat, water, gas, electricity, sewer, sewage treatment facilities and the like, all personal property taxes, real estate taxes, special assessments, and municipal or government charges, general, ordinary and extraordinary, of every kind and nature whatsoever, which may be levied, imposed, or assessed against the Leased Premises, or upon any improvements thereon, at any time after the Occupancy Date of this Lease for the period prior to the expiration of the term hereof, or any Renewal Term, if exercised.

  • Utility Services Company agrees to pay the full cost and expense associated with its use of all utilities, including but not limited to water, sanitary sewer, electric, storm drainage, and telecommunication services.

  • Excess Utility Use Landlord shall not be required to furnish electrical power that exceeds Tenant’s floor proportionate share of the electrical capacity of the Building floor on which the Premises are located made available for general tenant usage. If Tenant’s requirements for or consumption of electricity exceed the electricity to be provided by Landlord as described in Section 7.1, Landlord shall, at Tenant’s expense, make reasonable efforts to supply such service through the then-existing feeders and risers serving the Building and the Premises, provided the additional use of such feeders and risers caused by Tenant’s excess electrical requirements do not adversely affect Landlord’s ability to provide reasonable electrical service to the balance of the Building (as determined by Landlord in the exercise of its reasonable discretion); and Tenant shall pay to Landlord the cost of such service within 30 days after Landlord has delivered to Tenant an invoice therefor. Landlord may determine the amount of such additional consumption and potential consumption by any verifiable method, including installation of a separate meter in the Premises installed, maintained, and read by Landlord, at Tenant’s expense. Tenant shall not install any electrical equipment requiring special wiring or requiring voltage in excess of 110 volts unless approved in advance by Landlord, which approval shall not be unreasonably withheld. Tenant shall not install any electrical equipment requiring voltage in excess of the prorata capacity available to Tenant as of the date of this Lease unless approved in advance by Landlord, which approval may be withheld in Landlord’s sole discretion. The use of electricity in the Premises shall not exceed the capacity of existing feeders and risers to or wiring in the Premises. Any risers or wiring required to meet Tenant’s excess electrical requirements shall, upon Tenant’s written request, be installed by Landlord, at Tenant’s cost, if, in Landlord’s judgment, the same are necessary and shall not cause permanent damage to the Building or the Premises, cause or create a dangerous or hazardous condition, entail excessive or unreasonable alterations, repairs, or expenses, adversely affect Landlord’s ability to provide reasonable service to the balance of the Building, or interfere with or disturb other tenants of the Building. If Tenant (a) uses machines or equipment in the Premises or (b) operates within the Premises at a density, either of which (1) affects the temperature otherwise maintained by the air conditioning system or (2) otherwise overloads any utility, Landlord may install supplemental air conditioning units or other supplemental equipment in the Premises, and the cost thereof, including the cost of design, installation, operation, use, and maintenance, in each case plus an administrative fee of 15% of such cost, shall be paid by Tenant to Landlord within 30 days after Landlord has delivered to Tenant an invoice therefor. To the extent practicable, and subject to Landlord’s prior written consent, not to be unreasonably withheld, conditioned or delayed, Tenant shall have the right to elect, at Tenant’s sole cost and expense, to separately submeter electricity consumption in the entire Premises or any portion thereof. If Tenant elects, and Landlord approves, separately submetering the any portion of the Premises, Landlord and Tenant shall enter into an amendment to this Lease revising Tenant’s obligations for the payment of Electrical Costs, including separately submetered electricity usage, common area electricity usage, and any portions of the Premises not covered by the separate submeter(s).

  • Utility Charges Tenant shall pay or cause to be paid all charges for electricity, power, gas, oil, water and other utilities used in connection with the Leased Property.

Time is Money Join Law Insider Premium to draft better contracts faster.