Design and Construction Schedule. OVG shall cause the Arena to be designed in accordance with Section 14 and to be constructed in accordance with the approved Final Design, the Design Standards, the Permits and Approvals, and all applicable laws, and to be completed and opened for events in accordance with the Permits, Design, and Construction Schedule attached as Exhibit E, as it may be revised from time to time with the written approval of the City and as it may be extended by Force Majeure. “Force Majeure” shall mean, whenever any time period or deadline is set forth in the Design and Construction Schedule, such period or deadline shall be extended by the number of days that completion of an obligation is actually delayed due to acts of nature or of the public enemy; governmental action or inaction not reasonably anticipated, including by the City in iDRAFtT s capacity as a regulatory authority; acts of terrorism; fires; floods; tidal waves; epidemics; quarantine restrictions; freight embargoes; earthquakes; unusually severe weather; strikes or other substantial interruption of work because of labor disputes; inability to obtain materials or acceptable substitute materials on a timely basis, not reasonably anticipated; failure or delay in delivery of utilities serving the Premises not caused by, or outside the reasonable control of, the party claiming an extension; previously unknown environmental conditions discovered on or affecting the Premises or any portion thereof, in each case including any delay caused or resulting from the investigation or remediation of such conditions; existing unknown or newly discovered geotechnical conditions, including any delay caused or resulting from the investigation or remediation of such conditions; litigation that enjoins construction or other work on the Premises or any portion thereof, causes a lender to refuse to fund, disburse or accelerate payment on a loan, or prevents or suspends construction work except to the extent caused by the party claiming an extension; and any action or proceeding before any judicial, adjudicative, or legislative decision-making body, including any administrative appeal, that prevent the action that is being delayed, brought by a third party that challenges any Required Permit or Approval or other approval, action or consent required to implement the Development Project, provided the foregoing events shall only be considered Force Majeure to the extent the same (i) do not arise from the acts or negligent omissions of...
Design and Construction Schedule. In order to insure timely completion of construction of the Initial Leasehold Improvements, Subtenant shall prepare and Sublandlord shall approve a timetable whereby each party shall be obligated to meet certain dates in the design and construction process (the "Construction Schedule"). The approved Construction Schedule shall be attached hereto as Exhibit F. Subtenant's failure to meet any deadlines in the Construction Schedule shall not constitute a default hereunder.
Design and Construction Schedule. In order to ensure timely -------------------------------- completion of construction and outfitting of the Premises, Landlord and Tenant shall mutually agree to a timetable whereby each party shall be obligated to meet certain dates in the design and construction process.
Design and Construction Schedule. 2.1 The parties shall adhere to the following design and construction schedule. Action Deadline ------ -------- Tenant furnishes all December 22, 1999 information to Architect needed for Space Plan. Tenant submits proposed February 3, 2000 or 3 wks after Space Plan to Landlord architect is under contract, which- for approval. ever is later. Tenant furnishes all February 4, 2000 or 3 wks after information to Architect architect is under contract, which- needed for Construction ever is later. Documents (e.g., design finishes). Finishes Selected February 11, 2000 or 3 wks and one day after architect is under con- tract, whichever is later. Tenant submits proposed March 3, 2000 or 8 wks after archi- Construction Documents to Landlord tect is under contract, whichever for approval. is later.
Design and Construction Schedule. The schedule for design and construction of the Tenant Improvements shall be exclusively the responsibility of Tenant. Regardless of the date upon which the Premises are complete and ready for occupancy, the Rent Commencement Date shall remain as set forth in the Lease. RIDER 14.01 TENANT INSURANCE REQUIREMENT Tenant’s insurance requirements under the Lease are as follows:
Design and Construction Schedule. Prior to lease execution, Project Partners shall provide, to the City’s Community Development Director’s reasonable satisfaction, a design and construction schedule, demonstrating, at a minimum, the Peace Village will be constructed and completed within 7 years of the execution of the long-term lease, allowing for Primary and Secondary component phasing, and the potential for either Secondary component to be removed from the project description, without sacrificing the project as a whole, as described in section 5.
Design and Construction Schedule. OVG shall cause the Arena to be designed in accordance with Section 15 and to be constructed in accordance with the approved Final Design, the Design Standards, the Permits and Approvals, and all applicable laws, and to be completed and opened for events in accordance with the Permits, Design, and Construction
Design and Construction Schedule. SERVICE AGREEMENT NO. 2670 The Interconnection Customers shall, within twenty (20) calendar days after the date of this Agreement, prepare and submit to Affected System Operator and Connecting Transmission Owner for acceptance, a complete project schedule (Microsoft Project) showing in detail the design, procurement, construction and commissioning activities for the Project. This project schedule will become the baseline schedule for the Study. The Interconnection Customers shall provide a schedule update on a monthly basis showing progress as a percentage (%) complete against each baseline schedule activity. The Interconnection Customers shall provide a written report each month, with the updated schedule, outlining progress for all activities, explaining any activities delayed, and planned corrective action, if required, to restore delayed activities to meet the Study Baseline schedule. This baseline schedule will provide the basis for visibility of work progress and valid schedule information necessary to make timely management decisions about resources and action plans for recovery on the schedule.
Design and Construction Schedule. Section 106 consultation for the design of the BLC is planned to begin in early 2023. The target construction start date is 2024, with a target completion date of 2026. This schedule is subject to change with notification provided to the Signatories through the Monitoring and Reporting, Anti-Deficiency Act, and/or Design Consultation stipulations of this PA.
Design and Construction Schedule. Prior to lease execution, Smart Share shall provide, to the City’s Community Development Director’s reasonable satisfaction, a design and construction schedule, demonstrating, at a minimum, the Xxxxxxxx Village will be constructed and completed within 7 years of the execution of the long-term lease.
