DELIVERY OF ADDITIONAL ITEMS. At the Closing, each party shall deliver to the other such bills of sale, checks, assignments, share certificates, receipts and other documents, if any, as such other party or its counsel may reasonably request to effect the transactions contemplated by this Agreement.
DELIVERY OF ADDITIONAL ITEMS. At the Closing each party shall deliver to the other such bills of sale, instruments of assumptions of liabilities, checks, assignments, share certificates, receipts and other documents, as such other party or its counsel may reasonably request in connection with the transfer of assets, assumption of liabilities and liquidation contemplated by Section 1.
DELIVERY OF ADDITIONAL ITEMS. At the Closing, the Acquired Fund shall deliver to the Acquiring Fund such bills of sale, checks, assignments, share certificates, receipts and other documents, if any, as the Acquiring Fund or its counsel may reasonably request to effect the transactions contemplated by this Agreement. The Acquiring Fund shall deliver to the Acquired Fund such bills of sale, checks, assignments, share certificates, receipts and other documents, if any, the Acquired Fund or its counsel may reasonably request to effect the transactions contemplated by this Agreement.
DELIVERY OF ADDITIONAL ITEMS. Delivery dates for Additional Items shall reflect a schedule generally consistent with, and in any case no longer than, the timeframes necessary for manufacturing as reflected in the last two Batches of Customer Satellites or the last two Dispensers, or (iii) the last comparable Ground Station Equipment, as the case may be, Delivered prior to exercise of the applicable Option. The Contractor may adjust the Delivery dates in the reasonable judgment of the Contractor to reflect (x) reasonable delays in the event Customer does not order long lead items by specified dates, which dates have been established by the Contractor and notified by the Contractor to Customer at least sixty (60) days prior to the date the applicable orders need to be placed and based upon the ordering time periods in effect with suppliers for the applicable Option, or (y) any start-up period reasonably needed by the Contractor or Subcontractors if there shall be a gap between the Work being done under this Contract as then in effect and commencement of Work with respect to the applicable Option. In each case where there is expected to be such lead times or start-up period, the Contractor shall provide as part of the applicable Option an opportunity for Customer to pre-order by specified dates reasonable and customary long lead items specified by the Contractor to avoid or reduce the lead times or start-up period. Any pre-ordered long lead items not used in connection with the applicable Option shall be held as part of the inventory for the Rivada Program; provided, however, that if so requested by Customer, the Contractor shall use commercially reasonable efforts to use such long lead items for third-party customers and if so used the Contractor shall provide a rebate, offset or credit to Customer based upon the then reasonable benefit to the Contractor, net of reasonable documented costs actually incurred by the Contractor.
DELIVERY OF ADDITIONAL ITEMS. At the Closing, each party will deliver to the other party such bills of sale, checks, assignments, share certificates, receipts and other documents, if any, as such other party or its counsel may reasonably request to effect the transactions contemplated by this Agreement. The Target Fund will, from time to time, as and when reasonably requested by the Acquiring Fund, execute and deliver or cause to be executed and delivered all such assignments and other instruments, and will take or cause to be taken such further action as the Acquiring Fund may reasonably deem necessary or desirable in order to ultimately vest and confirm the Acquiring Fund’s title to and possession of all of the assets of the Target Fund and to otherwise carry out the intent and purpose of this Agreement.
