DELIVERIES OR PERFORMANCE. F.1. DELIVERIES OR PERFORMANCE CLAUSES Clauses regarding deliveries or performance for OASIS SB: FAR TITLE DATE 52.242-15 Stop Work Order AUG 1989 52.247-34 F.O.B. Destination NOV 1991 Clauses and other requirements regarding deliveries or performance shall be designated by the OCO at the task order level.
DELIVERIES OR PERFORMANCE. F.1 PERIOD OF PERFORMANCE The period of performance for MOA holders are as follows: MOA holders with BPA number starting with DTFAWA10A: Base period: Date of award – 9/30/2014 Option period 1: 10/1/2014 – 9/30/2019 Option period 2: 10/1/2019 – 9/30/2024 MOA holders with BPA number starting with DTFAWA11A or DTFAWA12A: Base period: Date of award – 9/30/2016 Option period 1: 10/1/2016 – 9/30/2019 Option period 2: 10/1/2019 – 9/30/2024 MOA holders with BPA number starting with DTFAWA13A: Base period: Date of award – 9/30/2019 Option period 1: 10/1/2019 – 9/30/2024 MOA holders with BPA numbers not listed above: Base period: Date of award – 9/30/2019 Option period 1: 10/1/2019 – 9/30/2024 MOA holders with BPA numbers starting with 693KA9-21-A or later: Base period: Date of award – 9/30/2024 MOA holders with reinstated BPA numbers: Option period: Date of modification issued – 9/30/2024 There are 20 program years for the period of performance. Program Year Period of Performance 1 Date of Award – 9/30/10 2 10/1/10 – 9/30/11 3 10/1/11 – 9/30/12 4 10/1/12 – 9/30/13 5 10/1/13 – 9/30/14 6 10/1/14 – 9/30/15 7 10/1/15 – 9/30/16 8 10/1/16 – 9/30/17 9 10/1/17 – 9/30/18 10 10/1/18 – 9/30/19 11 10/1/19 – 9/30/20 12 10/1/20 – 9/30/21 13 10/1/21 – 9/30/22 14 10/1/22 – 9/30/23 15 10/1/23 – 9/30/24 16 10/1/24 – 9/30/25 17 10/1/25 – 9/30/26 18 10/1/26 – 9/30/27 19 10/1/27 – 9/30/28 20 10/1/28 – 9/30/29 The Government may issue contracts or task orders at any time during the base or option periods of the MOA, as identified above. The Government may stop issuing contracts or task orders beyond program year 15.
DELIVERIES OR PERFORMANCE. F.1 FAR 52.252-2
DELIVERIES OR PERFORMANCE. F.1. 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx to see the links to the FAR. You may also use a network ―search engine‖ (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 Stop Work Order (AUG 1989) 52.242-17 Government Delay of Work (APR 1984)
DELIVERIES OR PERFORMANCE. 1. The research effort performed under this contract shall be conducted during the period from date of award through 31 March 2006. A final report will be prepared, submitted, reproduced and distributed by sixty days thereafter unless the contract is extended, in which case, the final report will be prepared in accordance with the terms of such extension.
DELIVERIES OR PERFORMANCE. F.1. DELIVERIES OR PERFORMANCE CLAUSES Clauses regarding deliveries or performance for OASIS: AR ITLE ATE 2.242-15 top Work Order UG 1989
DELIVERIES OR PERFORMANCE. F-1 FAR 52.242-15 STOP-WORK ORDER (AUG 1989) ALTERNATE I (APR 1984)
DELIVERIES OR PERFORMANCE. Contract court interpreters must be able to demonstrate to the satisfaction of the court that they are competent court interpreters who can render spoken or written court discourse accurately from English into the foreign or sign language and vice versa, and, as appropriate, perform interpretations in the simultaneous as well as consecutive modes or render sight translations with a high degree of accuracy. Contract court interpreters must possess a high level of language proficiency in both English and the foreign or sign language and have the knowledge, skill and ability to perform assignments in accordance with the requirements of federal courts. Services may be performed in or out-of-court. In the performance of services under this agreement, the contract court interpreter shall adhere to the provisions of this contract and any other conditions, policies, or procedures established by the court and attached to this contract, as well as the interpreter’s oath administered by the court. It is the responsibility of the contract court interpreter to ensure that he/she fully understands the scope of the assignment and the ramifications of accepting the assignment. The contract court interpreter shall recuse him or herself of any assignment that may be beyond the ability of the contract court interpreter or which may constitute a conflict of interest for the interpreter. The interpreter shall also advise the court if additional preparation time or other special conditions are required to ensure that the services can be rendered in a competent manner. The court has final authority to make decisions about assignments, including the use and rotation of team interpreters. The court also will make a determination if the contract interpreter should be issued an identification card, and shall set the terms and conditions for the use of such identification card.
DELIVERIES OR PERFORMANCE. F.1. PERIOD OF PERFORMANCE (BASE CONTRACT WITH OPTION(S))
DELIVERIES OR PERFORMANCE. F.1 FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference with the same force and effect as if they were given in full text. Full text can be accessed electronically at the following internet address: xxxxx://xxx.xxxxxxxxxxx.xxx/browsefar. FAR Clause Title and Date 52.242-15 Stop-Work Order (AUG 1989) (for other than cost-reimbursement task orders) and ALT I (APR 1984) (for cost-reimbursement task orders) 52.242-17 Government Delay of Work (APR 1984) 52.247-34 F.o.b. Destination (NOV 1991) 52.247-35 F.o.b. Destination, Within Consignee’s Premises (APR 1984) (End of Clause)
