DELAYS AND EXTENSIONS OF TIME. 8.3.1 If the Contractor is delayed at any time in progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner or by other causes which the Architect determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine.
Appears in 2 contracts
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner, ; or by changes ordered in the Work, ; or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's ’s control, ; or by delay authorized by the Owner pending mediation and arbitration; or by other causes which that the Architect determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine.
Appears in 2 contracts
Samples: Indemnity Agreement, www.fitnyc.edu
DELAYS AND EXTENSIONS OF TIME. 8.3.1 10.1 If the Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of eitherthe Owner, or of a separate contractor employed by the Owner, ; or by changes ordered in the Work, ; or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's ’s control, ; or by delay authorized by the Owner pending mediation and arbitration; or by other causes which that the Architect Owner determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine.
Appears in 1 contract
Samples: And Indemnification Agreement
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner, or by changes ordered in the Work, ; or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's control, ; or by delay authorized by the Owner pending mediation and arbitration; or by other causes which the Architect determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine.
Appears in 1 contract
Samples: 70.248.29.17:8085
DELAYS AND EXTENSIONS OF TIME. 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner pending mediation and arbitration, or by other causes which the Architect determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine.
Appears in 1 contract
Samples: Immunicon Corp
DELAYS AND EXTENSIONS OF TIME. 8.3.1 If the XXXX Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of the Owner or Architect, or of an employee of either, or of a separate contractor XXXX Contractor employed by the Owner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's ’s control, or by delay authorized by the Owner pending mediation and , or by other causes which the Architect and the Owner determines may justify delay, then the Contract Time shall may be extended by Change Order for such reasonable time as the Architect and the Owner may determine.
Appears in 1 contract
Samples: www.bidnet.com