DELAYS AND EXTENSIONS OF TIME. 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Appears in 156 contracts
Samples: Vermont Contract, Vermont Contract, Vermont Contract
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by any an act or failure to act by neglect of the State Owner or the Architect, or by any of an employee of either, or by any of a separate contractor employed by the State, Owner; or by changes ordered in the Work; or by labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatabledeliveries, unavoidable casualties, casualties or any other causes beyond the Contractor's control, ; or by delay authorized by the State Owner pending alternative dispute resolution proceedings, mediation and arbitration; or by any other cause which causes that the Architect determines may justify the justifY delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the Statemay determine.
Appears in 1 contract
Samples: STAMPS.COM Inc
DELAYS AND EXTENSIONS OF TIME. 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by any an act or failure to act by neglect of the State Owner or the Architect, or by any of an employee of either, or by any of a separate contractor employed by the StateOwner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatabledeliveries, unavoidable casualties, or any other causes beyond the Contractor's ’s control, or by delay authorized by the State Owner pending alternative dispute resolution proceedingsmediation, or by any other cause causes which the Architect recommends and the Owner determines may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the StateOwner may determine.
Appears in 1 contract
Samples: Form of Agreement
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by any an act or failure to act by neglect of the State Owner or the Architect, or by any of an employee of either, or by any of a separate contractor employed by the StateOwner, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatabledeliveries, unavoidable casualties, casualties or any other causes beyond the Contractor's control, or by delay authorized by the State Owner pending alternative dispute resolution proceedingsmediation and arbitration, or by any other cause causes which the Architect determines may justify the delay, then the applicable Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the Statemay determine.
Appears in 1 contract