Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.
Litigation History There shall be no consistent history of court/arbitral award decisions against the Tenderer, in the last (Specify years). All parties to the contract shall furnish the information in the appropriate form about any litigation or arbitration resulting from contracts completed or ongoing under its execution over the year’s specified. A consistent history of awards against the Tenderer or any member of a JV may result in rejection of the tender.
Defense of Claims Subject to the provisions of applicable policies of directors’ and officers’ liability insurance, if any, the Company shall be entitled to participate in the defense of any Indemnifiable Claim or to assume or lead the defense thereof with counsel reasonably satisfactory to the Indemnitee; provided that if Indemnitee determines, after consultation with counsel selected by Indemnitee, that (a) the use of counsel chosen by the Company to represent Indemnitee would present such counsel with an actual or potential conflict, (b) the named parties in any such Indemnifiable Claim (including any impleaded parties) include both the Company and Indemnitee and Indemnitee shall conclude that there may be one or more legal defenses available to him or her that are different from or in addition to those available to the Company, (c) any such representation by such counsel would be precluded under the applicable standards of professional conduct then prevailing, or (d) Indemnitee has interests in the claim or underlying subject matter that are different from or in addition to those of other Persons against whom the Claim has been made or might reasonably be expected to be made, then Indemnitee shall be entitled to retain separate counsel (but not more than one law firm plus, if applicable, local counsel in respect of any particular Indemnifiable Claim for all indemnitees in Indemnitee’s circumstances) at the Company’s expense. The Company shall not be liable to Indemnitee under this Agreement for any amounts paid in settlement of any threatened or pending Indemnifiable Claim effected without the Company’s prior written consent. The Company shall not, without the prior written consent of the Indemnitee, effect any settlement of any threatened or pending Indemnifiable Claim which the Indemnitee is or could have been a party unless such settlement solely involves the payment of money and includes a complete and unconditional release of the Indemnitee from all liability on any claims that are the subject matter of such Indemnifiable Claim. Neither the Company nor Indemnitee shall unreasonably withhold its consent to any proposed settlement; provided that Indemnitee may withhold consent to any settlement that does not provide a complete and unconditional release of Indemnitee.
INSURANCE AND LIABILITIES TO THIRD PARTIES 8.1 The Contractor shall provide and thereafter maintain insurance against all risks in respect of its property and any equipment used for the execution of this Contract.
Contractor’s Xxxxxxxx to City Compensation. The Contractor shall send invoices to the City on a monthly or bi-monthly basis for the amounts to be paid pursuant to this contract. Each invoice shall document, to the reasonable satisfaction of the City: such information as may be reasonably requested by the City. Within 60 days after the City receives an invoice, the City shall send the Contractor a check in payment for all undisputed amounts contained in the invoice.
Institution of Legal Actions Any legal actions related to or arising out of this Agreement must be instituted in the District Court of Xxxxxxx County, Kansas or, if federal jurisdiction exists, in the Federal District Court in the District of Kansas.
Disputes between the Contracting Parties 1. Any dispute between the Contracting Parties concerning the interpretation or application of this Agreement shall, as far as possible, be settled through negotiation.
PROFESSORS AND TEACHERS A professor or teacher who makes a temporary visit to a Contracting State for a period not exceeding two years for the purpose of teaching or conducting research at a university, college, school or other educational institution, and who is, or immediately before such visit was, a resident of the other Contracting State shall be exempt from tax in the first-mentioned Contracting State in respect of remuneration for such teaching or research.
Defense and Indemnification a. The Contractor hereby agrees to defend, indemnify, reimburse and hold harmless the City, its appointed and elected officials, agents and employees for, from and against all liabilities, claims, judgments, suits or demands for damages to persons or property arising out of, resulting from, or relating to the work performed under this Agreement (“Claims”), unless such Claims have been specifically determined by the trier of fact to be the sole negligence or willful misconduct of the City. This indemnity shall be interpreted in the broadest possible manner to indemnify the City for any acts or omissions of the Contractor or its subcontractors either passive or active, irrespective of fault, including the City’s concurrent negligence whether active or passive, except for the sole negligence or willful misconduct of the City.
