Defects Due to Customer Actions or Omissions Sample Clauses

Defects Due to Customer Actions or Omissions. If a defect or malfunction occurs in any Product as a result of (1) repairs, changes, modifications or alterations not authorized or approved by ES&S, (2) accident, theft, vandalism, neglect, abuse or use that is not in accordance with instructions or specifications furnished by ES&S or (3) causes beyond the reasonable control of ES&S or Customer, including acts of God, fire, flooding, riots, acts of war, terrorism or insurrection, labor disputes, transportation delays, governmental regulations, and utility or communication interruptions, rodent infestation, or if Customer does not notify ES&S within 72 hours after it knows of the defect or malfunction, Customer shall pay ES&S for the Repair Services at ES&S’ then-current rates, as well as for the cost of all parts used in connection with such Repair Services.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Defects Due to Customer Actions or Omissions. If a defect or malfunction occurs in any Product as a result of (1) repairs, changes, modifications or alterations not authorized or approved by ES&S, (2) accident, theft, vandalism, neglect, abuse or use that is not in accordance with instructions or specifications furnished by ES&S or (3) causes beyond the reasonable control of ES&S or Customer, including acts of God, fire, riots, acts of war, terrorism or insurrection, labor disputes, transportation delays, governmental regulations, and utility or communication interruptions, or if Customer does not notify ES&S within 24 hours after it knows of the defect or malfunction or is otherwise not in compliance with its obligations hereunder, Customer shall pay ES&S for the Remedial Maintenance Services at ES&S’ then-current rates, as well as for the cost of all parts used in connection with such Remedial Maintenance Services.
Sample 1Sample 2
Defects Due to Customer Actions or Omissions. If a defect or malfunction occurs in any Product as a result of (1) repairs, changes, modifications or alterations not authorized or approved by ES&S, (2) use, modification, dismantling, disassembly, or transfer to third party without ES&S’s prior written consent, (3) accident, theft, vandalism, neglect, abuse, liquid contact, use of adhesive materials on ballots or use that is not in accordance with instructions or specifications furnished by ES&S or (4) causes beyond the reasonable control of ES&S or Customer, including acts of God, fire, floods, riots, acts of war, terrorism or insurrection, government acts or orders; epidemics, pandemics or outbreak of communicable disease; quarantines; national or regional emergencies, labor disputes, transportation delays, governmental regulations and utility or communication interruptions, rodent infestation, or if Customer does not notify ES&S within 72 hours after it knows of the defect or malfunction, Customer shall pay ES&S for the Repair Services at ES&S’ then-current rates, as well as for the cost of all parts used in connection with such Repair Services.
Sample 1Sample 2
Defects Due to Customer Actions or Omissions. If a defect or malfunction occurs in any Product as a result of (1) repairs, changes, modifications or alterations not authorized or approved by PES, (2) accident, theft, vandalism, neglect, abuse or use that is not in accordance with instructions or specifications furnished by PES or (3) causes beyond the reasonable control of PES or Customer, including acts of God, fire, riots, acts of war, terrorism or insurrection, labor disputes, transportation delays, governmental regulations, and utility or communication interruptions, or if Customer does not notify PES within 24 hours after it knows of the defect or malfunction or is otherwise not in compliance with its obligations hereunder, Customer shall pay PES for the Remedial Maintenance Services at PES‟ then-current rates, as well as for the cost of all parts used in connection with such Remedial Maintenance Services.
Sample 1
Defects Due to Customer Actions or Omissions. If a defect or malfunction occurs in any Product as a result of (1) repairs, changes, modifications or alterations not authorized or approved by ES&S, (2) use, modification, dismantling, disassembly, or transfer to third party without ES&S’s prior written consent, (3) accident, theft, vandalism, neglect, abuse or use that is not in accordance with instructions or specifications furnished by ES&S or (4) causes beyond the reasonable control of ES&S or Customer, including acts of God, fire, floods, riots, acts of war, terrorism or insurrection, government acts or orders; epidemics, pandemics or outbreak of communicable disease; quarantines; national or regional emergencies, labor disputes, transportation delays, governmental regulations and utility or communication interruptions, rodent infestation, or if Customer does not notify ES&S within 72 hours after it knows of the defect or malfunction, Customer shall pay ES&S for the Repair Services at ES&S’ then-current rates, as well as for the cost of all parts used in connection with such Repair Services.
Sample 1
Defects Due to Customer Actions or Omissions. If a defect or malfunction occurs in any Product as a result of (1) repairs, changes, modifications or alterations not authorized or approved by ES&S, (2) accident, theft, vandalism, neglect, abuse or use that is not in accordance with instructions or specifications furnished by ES&S or (3) causes beyond the reasonable control of ES&S or Customer, including acts of God, fire, floods, riots, acts of war, terrorism or insurrection, government acts or orders; epidemics, pandemics or outbreak of communicable disease; quarantines; national or regional emergencies, labor disputes, transportation delays, governmental regulations and utility or communication interruptions, rodent infestation, or if Customer does not notify ES&S within 72 hours after it knows of the defect or malfunction, Customer shall pay ES&S for the Repair Services at ES&S’ then-current rates, as well as for the cost of all parts used in connection with such Repair Services.
Sample 1

Related to Defects Due to Customer Actions or Omissions

  • Delays or Omissions No delay or omission to exercise any right, power or remedy accruing to any party under this Agreement, upon any breach or default of any other party under this Agreement, shall impair any such right, power or remedy of such non-breaching or non-defaulting party nor shall it be construed to be a waiver of any such breach or default, or an acquiescence therein, or of or in any similar breach or default thereafter occurring; nor shall any waiver of any single breach or default be deemed a waiver of any other breach or default theretofore or thereafter occurring. Any waiver, permit, consent or approval of any kind or character on the part of any party of any breach or default under this Agreement, or any waiver on the part of any party of any provisions or conditions of this Agreement, must be in writing and shall be effective only to the extent specifically set forth in such writing. All remedies, either under this Agreement or by law or otherwise afforded to any party, shall be cumulative and not alternative.

  • Acts or Omissions Vendor shall indemnify and hold harmless the State of Texas and Customers, AND/OR THEIR OFFICERS, AGENTS, EMPLOYEES, REPRESENTATIVES, CONTRACTORS, ASSIGNEES, AND/OR DESIGNEES FROM ANY AND ALL LIABILITY, ACTIONS, CLAIMS, DEMANDS, OR SUITS, AND ALL RELATED COSTS, ATTORNEY FEES, AND EXPENSES arising out of, or resulting from any acts or omissions of the Vendor or its agents, employees, subcontractors, Order Fulfillers, or suppliers of subcontractors in the execution or performance of the Contract and any Purchase Orders issued under the Contract. THE DEFENSE SHALL BE COORDINATED BY VENDOR WITH THE OFFICE OF THE ATTORNEY GENERAL WHEN TEXAS STATE AGENCIES ARE NAMED DEFENDANTS IN ANY LAWSUIT AND VENDOR MAY NOT AGREE TO ANY SETTLEMENT WITHOUT FIRST OBTAINING THE CONCURRENCE FROM THE OFFICE OF THE ATTORNEY GENERAL. VENDOR AND THE CUSTOMER AGREE TO FURNISH TIMELY WRITTEN NOTICE TO EACH OTHER OF ANY SUCH CLAIM.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

  • WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit F Resume Self-Certification Form Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit G Contractor Selection Justification Form Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: _ Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: _ Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit H Contractor Performance Survey Note: This is an example of the questions contained in the Contractor Performance Survey. The actual survey will be provided in electronic form. Customers shall complete this Contractor Performance Survey for each Contractor on a quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated the Scope of Work. Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following: Quality of Service

  • Liability for Acts or Omissions of Third Parties Neither BellSouth nor Mpower shall be liable for any act or omission of another telecommunications company providing a portion of the services provided under this Agreement.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Disclaimer of Liability for Damages IN NO EVENT WILL VOIP SYSTEMS USA, ITS OFFICERS, DIRECTORS, EMPLOYEES, AFFILIATES OR AGENTS OR ANY OTHER SERVICE PROVIDER WHO FURNISHES SERVICES TO YOU IN CONNECTION THE SERVICE BE LIABLE FOR ANY DIRECT, INCIDENTAL, INDIRECT, SPECIAL, PUNITIVE, EXEMPLARY OR CONSEQUENTIAL DAMAGES, OR FOR ANY OTHER DAMAGES, INCLUDING BUT NOT LIMITED TO PERSONAL INJURY, WRONGFUL DEATH, PROPERTY DAMAGE, LOSS OF DATA, LOSS OF REVENUE OR PROFITS, OR DAMAGES ARISING OUT OF OR IN CONNECTION WITH THE USE OR INABILITY TO USE THE SERVICE, INCLUDING INABILITY TO ACCESS EMERGENCY SERVICE PERSONNEL THROUGH THE 911 DIALING SERVICE OR TO OBTAIN EMERGENCY HELP. THE LIMITATIONS SET FORTH HEREIN APPLY TO CLAIMS FOUNDED IN BREACH OF CONTRACT, BREACH OF WARRANTY, PRODUCT LIABILITY, TORT AND ANY AND ALL OTHER THEORIES OF LIABILITY AND APPLY WHETHER OR NOT WE WERE INFORMED OF THE LIKELIHOOD OF ANY PARTICULAR TYPE OF DAMAGES.

  • Liability for Damage Each party shall be liable to the other for all damage to the property of the other negligently, recklessly or intentionally caused by that party (or their agents, employees or invitees), except to the extent the loss is insured and subrogation is waived under the owner's policy.

Time is Money Join Law Insider Premium to draft better contracts faster.