Damage During Last Year of Lease Term Sample Clauses

Damage During Last Year of Lease Term. Without limiting Landlord’s rights under Section 12.2, in the event the Building or Demised Premises shall be substantially damaged during the last year of the term of this Lease, either Tenant or Landlord may elect to terminate this Lease effective upon giving notice of such election, in writing, to the other within thirty (30) days after the happening of the fire or other casualty.
Sample 1Sample 2See All (7)
AutoNDA by SimpleDocs
Damage During Last Year of Lease Term. Notwithstanding anything set forth in this Lease to the contrary, if the Premises is damaged or destroyed by Casualty in excess of thirty percent (30%) of the full replacement cost of the Premises during the last year of the then current Term, either party may terminate this Lease as of the date of such damage or destruction by giving written notice to the other party within ninety (90) days following the date of such damage or destruction. Further, if Tenant has any outstanding option to renew the Term, and the period for exercising such outstanding option to renew has not yet expired, Tenant may void Landlord’s election to terminate this Lease as provided in the foregoing sentence, by delivering written notice to Landlord exercising such option to renew. In no event shall such revocation of the termination notice apply to Landlord’s election to terminate this Lease as provided in this Section 11.9.
Sample 1
Damage During Last Year of Lease Term. Without limiting Landlord’s rights under Section 12.2, in the event the Building or Demised Premises shall, in Landlord’s reasonable judgment, be substantially damaged during the last year of the Term of this Lease, Landlord may elect either to rebuild or repair the Demised Premises or to terminate this Lease effective upon giving notice of such election, in writing, to Tenant within thirty (30) days after the happening of the fire or other casualty; provided, however, that if Tenant has exercised its right to extend the Term, Landlord shall only have the rights set forth in this Section 12.3 during the last year of any Renewal Term.
Sample 1
Damage During Last Year of Lease Term. Without limiting Landlord’s or Tenant’s rights under Section 12.2, in the event the Building or Demised Premises shall, in Landlord’s reasonable judgment, be substantially damaged during the last year of the term of this Lease, either party may elect to terminate this Lease effective upon giving notice of such election, in writing, to the other party within thirty (30) days after the happening of the fire or other casualty. For purposes of this Section 12.3 “substantially damaged” shall mean that, in Landlord’s reasonable judgment, the Demised Premises cannot be restored to tenantable condition within 60 days after the casualty.
Sample 1
Damage During Last Year of Lease Term. Notwithstanding anything to the contrary contained in Section 17.1, in the event the Premises shall be damaged or destroyed by casualty within one (1) year of the Expiration Date and the cost to complete the Repair and Restoration is in excess of thirty percent (30%) of the full replacement cost of the Premises (excluding the cost of excavations, footings and foundations) or the Repair and Restoration cannot be completed within ninety (90) days from the date of casualty, either party shall have the option to terminate this Lease by giving written notice to the other party within thirty (30) days following the date of the casualty effective on the date of such notice.
Sample 1

Related to Damage During Last Year of Lease Term

  • Term of Lease This Lease shall commence 1st day of May, 2022 to 30th day of April, 2023, unless renewed or extended pursuant to the terms herein.

  • Lease Year Lease Year" means each consecutive twelve-month period beginning with the Commencement Date, except that if the Commencement Date is not the first day of a calendar month, then the first Lease Year shall be the period from the Commencement Date through the final day of the twelve months after the first day of the following month, and each subsequent Lease Year shall be the twelve months following the prior Lease Year.

  • Sublease Term The term of the Sublease (“Sublease Term”) commences on the later to occur of (1) Sublandlord’s receipt of Prime Landlord’s written consent to this Sublease, and (2) October 1, 2009 (“Sublease Commencement Date”); and expires on January 28, 2018 (“Sublease Expiration Date”; i.e., the day prior to the Termination Date pursuant to the Prime Lease). Sublandlord shall deliver the Subleased Premises “broom clean” and free of all of Sublandlord’s personal property (other than the F&F (defined in Section 2(f))) and debris, but otherwise in “AS IS, WHERE IS” condition on the Sublease Commencement Date; provided that Subtenant shall not be responsible for, or required to remedy, any violation of any applicable law, or any condition or state of facts, with respect to the Subleased Premises, the Building or the Land existing on or prior to the Sublease Commencement Date. Sublandlord is not required to perform any work to prepare the Subleased Premises for Subtenant’s intended use. If (i) for any reason Sublandlord has not received Prime Landlord’s written consent to this Sublease in form required by Section 15(i) below by the date which is sixty (60) days from the date hereof, or (ii) Prime Landlord elects to terminate the Prime Lease in respect of the Subleased Premises pursuant to Prime Landlord’s recapture right set forth in Section 16.5 of the Prime Lease, then in the case of (i), then Sublandlord and Subtenant each may elect at any time thereafter to terminate this Sublease by written notice to the other, whereupon the parties shall deem this Sublease to be null and void and of no effect (except for those provisions expressly stated herein to survive a termination), and in the case of (ii) the Sublease will be deemed terminated in accordance with Section 16.5 of the Prime Lease.

  • Extension of Lease Term The Original Lease Term is hereby extended for a period of eighteen (18) months continuing through and including November 30, 2022 (the “Extension Term” and the Original Lease Term as so extended by the Extension Term, the “Lease Term”).

  • Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

  • Lease Term The terms and provisions of this Lease shall be effective as of the date of this Lease. The term of this Lease (the “Lease Term”) shall commence on the “Lease Commencement Date,” as that term is set forth in Section 3.2 of the Summary, and shall terminate on the “Lease Expiration Date,” as that term is set forth in Section 3.3 of the Summary, unless this Lease is sooner terminated as hereinafter provided. Tenant hereby acknowledges that the Premises are currently occupied by another tenant of the Building. If Landlord is unable for any reason to deliver possession of the Premises to Tenant on any specific date , then Landlord shall not be subject to any liability for its failure to do so, and such failure shall not affect the validity of this Lease or the obligations of Tenant hereunder. For purposes of this Lease, the term “Lease Year” shall mean each consecutive twelve (12) month period during the Lease Term. At any time during the Lease Term, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit C, attached hereto, as a confirmation only of the information set forth therein, which Tenant shall execute and return to Landlord within ten (10) business days of receipt thereof; provided, however, Tenant’s failure to execute and return such notice to Landlord within such time shall be conclusive upon Tenant that the information set forth in such notice is as specified therein. In addition to the foregoing, subject to any delays caused by Tenant or any Tenant Parties and events of Force Majeure, if Landlord fails to tender possession of the Premises to Tenant on or before January 2, 2015 (the “Base Rent Delivery Date”), Tenant shall be entitled to one (1) day of per diem Base Rent abatement for each day commencing on the day after the Base Rent Delivery Date and ending on the date Landlord so tenders possession of the Premises to Tenant. Any such Base Rent Abatement shall be separate from and in addition to any Rent Abatement described in Section 3.2 below.

  • Term of the Lease 4.2.1 The term of the Lease shall be sixty (60) months commencing on the Acceptance date.

  • Term of Leases All Leases for residential dwelling units with respect to the Mortgaged Property satisfy each of the following conditions:

  • Initial Lease Term The terms and provisions of this Lease shall be effective as of the date of this Lease except for the provisions of this Lease relating to the payment of Rent. The term of this Lease (the “Lease Term”) shall be as set forth in Section 3.1 of the Summary, shall commence on the date (the “Lease Commencement Date”) that is the earlier to occur of (i) the date Tenant commences to conduct business in any portion of the Premises, and (ii) the of “Substantial Completion”, as that term is defined in this Article 2, of the Premises by Landlord, and shall terminate on the date determined in accordance with Section 3.3 of the Summary (the “Lease Expiration Date”) unless this Lease is sooner terminated as hereinafter provided. For purposes of this Lease, “Substantial Completion” of the Premises shall occur upon the completion of construction, as reasonably determined by Landlord, of the “Tenant Improvements,” as that term is defined in the Tenant Work Letter, in the Premises pursuant to the plans and drawings which are prepared and approved pursuant to the terms of the Tenant Work Letter and the issuance of a temporary certificate of occupancy or legal equivalent, with the exception of any Punchlist Items (as defined below) and any Tenant fixtures, work-stations, built-in furniture, or equipment to be installed by Tenant or under the supervision of Contractor (as defined in Section 3 of the Tenant Work Letter). “Punchlist Items” shall mean only commercially reasonable punchlist items, the non-completion of which does not prevent the issuance of a temporary certificate of occupancy or legal equivalent or unreasonably interfere with Tenant’s use or occupancy of the Premises, and which punchlist items shall be corrected promptly by Landlord (within thirty (30) days following Landlord’s receipt of written notice thereof from Tenant) without unreasonable interference with Tenant’s use of or access to or from the Premises. It is anticipated that the Lease Commencement Date will occur within sixteen (16) weeks after mutual execution of this Lease (such date, the “Target Commencement Date”), but this Lease shall not be void, voidable or subject to termination, nor shall Landlord be liable to Tenant for any loss or damage, resulting from Landlord’s inability to deliver the Premises to Tenant by any particular date, except as hereinafter provided. Notwithstanding anything to the contrary in this Lease, if the Lease Commencement Date does not occur within 60 days after the Target Commencement Date, other than due to Tenant Delay (as defined in the Tenant Work Letter) or Force Majeure, then Tenant, at its option, may terminate this Lease by written notice to Landlord given at any time after the expiration of such 60-day period but before the Lease Commencement Date actually occurs. In the event of such termination by Tenant, the first month’s Base Rent, Tenant’s Share of Direct Expenses paid by Tenant and the Security Deposit shall be fully refunded to Tenant (subject to Landlord’s right to draw upon such Security Deposit as provided in Article 21 below) and neither party shall have any further obligations hereunder. At any time during the Lease Term, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit “C”, attached hereto, as a confirmation only of the information set forth therein, which Tenant shall (absent manifest error) execute and return to Landlord within five (5) business days of receipt thereof.

  • Base Term Commencing on the Expansion Premises Commencement Date, the defined term “Base Term” on page 1 of the Lease is deleted in its entirety and replaced with the following:

Time is Money Join Law Insider Premium to draft better contracts faster.