DAMAGE OR DESTRUCTION OF PREMISES (a) If the Premises or any part thereof shall be damaged by fire or other insured casualty, then, subject to the last paragraph of this Section, Landlord shall proceed with diligence, subject to then applicable statutes, building codes, zoning ordinances and regulations of any governmental authority, and at the expense of Landlord (but only to the extent of insurance proceeds made available to Landlord by any mortgagee of the Building and any ground lessor) to repair or cause to be repaired such damage (other than any Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and Tenant Work, which Tenant shall promptly commence, and proceed with diligence, to restore). All such repairs made necessary by any act or omission of Tenant shall be made at the Tenant’s expense to the extent that the cost of such repairs are less than the deductible amount in Landlord’s insurance policy. All repairs to and replacements of Tenant Property not deemed to be fixtures covered by Landlord’s property insurance and any Initial Tenant Improvements and Tenant Work shall be made by and at the expense of Tenant. The cost of any repairs performed under this Section by Landlord at Tenant’s request and at Tenant’s expense (including costs of design fees, financing, and charges for administration, overhead and construction management services by Landlord and Landlord’s contractor) shall constitute Additional Rent hereunder. If the Premises or any part thereof shall have been rendered unfit for use and occupation hereunder by reason of such damage, the Base Rent or a just and proportionate part thereof, according to the nature and extent to which the Premises shall have been so rendered unfit, shall be abated until the Premises (except as to Tenant Property, Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and any Tenant Work) shall have been restored as nearly as practicable to the condition in which they were immediately prior to such fire or other casualty; and that if and to the extent Landlord shall be unable to collect the insurance proceeds (including rent insurance proceeds) applicable to such damage because of some action or inaction on the part of Tenant, or the employees, licensees or invitees of Tenant, the cost of repairing such damage shall be paid by Tenant and there shall be no abatement of rent. Landlord shall not be liable for delays in the making of any such repairs that are due to government regulation, casualties, and strikes, unavailability of labor and materials, delays in obtaining insurance proceeds, and other causes beyond the reasonable control of Landlord, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. If the Premises or the Building are substantially damaged so as to prevent Tenant from using the Premises for the Permitted Use and the Premises have not been restored to the condition required pursuant to the terms of this Lease within two hundred and seventy (270) days following said casualty (or if such casualty occurs during the last 18 months of the term, within ninety (90) days after the date of such casualty), then Tenant may terminate this Lease upon thirty (30) days written notice to Landlord unless Landlord shall substantially complete such repair and restoration within such thirty (30) day period in which event Tenant’s termination shall be void and of no further force or effect.
Damage or Destruction 17.1 If the Premises or the Building are totally or partially damaged or destroyed thereby rendering the Premises totally or partially inaccessible or unusable, then Landlord shall diligently repair and restore the Premises and the Building to substantially the same condition they were in prior to such damage or destruction; provided, however, that if in Landlord’s reasonable judgment such repair and restoration cannot be completed within two hundred seventy (270) days after the occurrence of such damage or destruction (taking into account the time needed for effecting a satisfactory settlement with any insurance company involved, removal of debris, preparation of plans and issuance of all required governmental permits), then Landlord shall have the right to terminate this Lease by giving written notice of termination within forty five (45) days after the occurrence of such damage or destruction. If this Lease is terminated pursuant to this Article, then rent shall be apportioned (based on the portion of the Premises which is usable or used after such damage or destruction) and paid to the later of the date of termination or the date Tenant completely vacates and abandons the Premises on account of such damage and (if applicable) Landlord shall be entitled to any insurance proceeds received by Tenant that are attributable to Landlord’s Work and other improvements insured or required to be insured by Tenant that would remain in the Premises at the end of the Lease Term. If this Lease is not terminated as a result of such damage or destruction, then until such repair and restoration of the Premises are substantially complete, Tenant shall be required to pay rent only for the portion of the Premises that is usable while such repair and restoration are being made; provided, however, that (x) if such damage or destruction was caused by the act or omission of Tenant or any Agent of Tenant, then Tenant shall not be entitled to any such rent reduction and (y) if Tenant fails to immediately pay over to Landlord insurance proceeds when received from Tenant’s insurance any such rent abatement shall end on the date when Landlord would have been able to substantially complete repair and restoration of the Premises had Tenant timely paid Landlord such insurance proceeds. After receipt of all insurance proceeds (including proceeds of insurance maintained by Tenant), Landlord shall proceed with and bear the expenses of such repair and restoration of the Premises and the Building; provided, however, that (a) if such damage or destruction was caused by the act or omission of Tenant or any Agent of Tenant, then Tenant shall pay Landlord’s deductible and the amount by which such expenses exceed the insurance proceeds, if any, actually received by Landlord on account of such damage or destruction (or, if Landlord fails to maintain the insurance required by Section 13.3, that Landlord would have received had Landlord maintained such insurance required by Section 13.3), (b) Tenant shall pay the amount by which the cost of restoring any item which Landlord is required to restore and Tenant is required to insure exceeds the insurance proceeds received with respect thereto, and (c) Landlord shall not be required to repair or restore any tenant improvements installed in the Premises (except to the extent Landlord receives proceeds therefor from Tenant’s insurance), any Alterations or any other contents of the Premises (including Tenant’s trade fixtures, decorations, furnishings, equipment or personal property). Notwithstanding anything herein to the contrary, Landlord shall have the right to terminate this Lease if (1) insurance proceeds plus deductibles are insufficient to pay the full cost of such repair and restoration (so long as Landlord maintains the insurance required by Section 13.3), (2) the holder of any Mortgage fails or refuses to make such insurance proceeds available for such repair and restoration, (3) zoning or other applicable Laws or regulations do not permit such repair and restoration, or (4) the damage to the Building exceeds thirty five percent (35%) of the replacement value of the Building.
Damage, Destruction and Condemnation In the event that at any time during the Term the whole or part of the Facility shall be damaged or destroyed, or taken or condemned by a competent authority for any public use or purpose, or by agreement to which the Lessee and those authorized to exercise such right are parties, or if the temporary use of the Facility shall be so taken by condemnation or agreement (a “Loss Event”):
Damage, Destruction or Condemnation If the Dock or any portion thereof is at any time destroyed or damaged by a casualty, or if any portion of the Dock or adjacent parcels are taken pursuant to the exercise or threatened exercise of the power of eminent domain (including a conveyance in lieu thereof), Port may elect to terminate this Agreement.
Damage or Loss of Equipment 2.2.1. All devices are covered by a manufacturer’s warranty. The warranty covers manufacturer’s defects and normal use of the device. It does not cover negligence, abuse or malicious damage.
Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility-consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. SAMPLE
Data Destruction When no longer needed, all County PHI or PI must be cleared, purged, or destroyed consistent with NIST Special Publication 800-88, Guidelines for Media Sanitization such that the PHI or PI cannot be retrieved.
ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.
