CPM Schedule Submission Sample Clauses

CPM Schedule Submission. On or prior to execution of this Agreement, Contractor shall prepare and submit to Owner for its review and written approval a detailed critical path method schedule for the Project (“CPM Schedule”). Owner may issue written comments, proposed changes and/or written approval or disapproval of such CPM Schedule. The CPM Schedule shall, at a minimum, (i) include separate activities for each portion of the Project, (ii) be fully integrated and shall be consistent with the Project Schedule, and (iii) show an uninterrupted critical path from the NTP through Substantial Completion and Final Completion of the Project. With respect to each activity in the CPM Schedule, the CPM Schedule shall show the activity number, activity description, early start and early finish dates, late start and late finish dates, duration, total float value, and responsible Contractor, Subcontractor or other parties. The CPM Schedule shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Required Mechanical Completion Date, Required Substantial Completion Date, and the Required Final Completion Date. The CPM Schedule shall be submitted in hard copy and also in its native electronic format, provided on a computer diskette. Once the CPM Schedule and the required submittals have been reviewed and approved by Owner, such version of the CPM Schedule shall be the baseline CPM Schedule for the Work.
Sample 1Sample 2
AutoNDA by SimpleDocs
CPM Schedule Submission. Within sixty (60) Days after issuance of the GTG LNTP, Contractor shall prepare and submit to Owner for its review a preliminary critical path method schedule for the Work using Oracle Primavera P6 and showing evidence of the preliminary incorporation of the Siemens engineering deliverable dates within Contractor’s schedule for engineering and construction. Thereafter, Contractor shall submit a detailed critical path method schedule for the Work, for Owner’s review and written approval, no later than one hundred twenty (120) Days after issuance of GTG LNTP which meets the requirements set forth in Attachment U. This detailed critical path method schedule (as well as, for the avoidance of doubt, any CPM Performance Measurement Baseline Schedule and Monthly Updated CPM Schedule) shall adhere to the guidelines set forth in this Section 5.4, including Attachment U.
Sample 1Sample 2
CPM Schedule Submission. Within forty-five (45) Days after the Effective Date, Contractor shall prepare and submit to Owner for its review and written approval a detailed resource/man-hour loaded critical path method schedule for the Project using Primavera Project Planner (P6) version 8.2 or later (“CPM Schedule”). Owner may issue written comments, proposed changes or written approval or disapproval of such CPM Schedule. The CPM Schedule shall, at a minimum, (i) include separate activities for each portion of the Project (including engineering, procurement and construction, along with non-physical activities related to the Work, such as submittal and approval of Drawings and Specifications, procurement of Equipment and inspection and testing of the Work, and obtaining Permits), (ii) be fully integrated and shall be consistent with the Milestone Dates, (iii) be detailed at a level 3 (with each activity containing Work for one discipline or craft having a maximum twenty (20) Day duration) for all activities for the Project, (iv) fully incorporate all Major Subcontractor schedules for the performance of their work (including off-site Subcontractors, suppliers and fabricators), (v) show the duration, early/late start dates, early/late finish dates and available float for each activity, activity number, activity description and responsible Contractor or Subcontractor, and an uninterrupted critical path from the NTP through each Milestone Date, including Mechanical Completion, Substantial Completion and Final Completion of the Project, (vi) be cost-loaded to reflect Contractor’s expected payments during the progress of the Work; and (vii) be man-hour loaded to reflect the projected manpower to be used per activity (whether provided by Contractor or any Subcontractor or Sub-subcontractor), showing the number of personnel, the positions and titles of such personnel, and a general description of the Work being performed. With respect to each activity in the CPM Schedule, the CPM Schedule shall show the activity number, activity description, early start and early finish dates, late start and late finish dates, duration, total float value, and responsible Contractor, Subcontractor or other parties (including Owner and Owner’s other contractors). The CPM Schedule shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Milestone Dates, including the Guaranteed Substantial Completion Date and the Guaranteed Final Completion Date. The CPM Schedule ...
Sample 1
CPM Schedule Submission. On or prior to the Start Date, Contractor shall prepare and submit to Owner for its review and written approval a detailed critical path method schedule for the Project using Microsoft Project ("CPM Schedule"). Owner may issue written comments, proposed changes and/or written approval or disapproval of such CPM Schedule. The CPM Schedule shall, at a minimum, (i) include separate activities for each portion of the Project (including engineering, procurement and construction, along with non-physical activities related to the Work), (ii) be fully integrated and shall be consistent with the Project Schedule, and (iii) show an uninterrupted critical path from the notice to proceed through Commercial Operation, Substantial Completion and Final Completion. With respect to each activity in the CPM Schedule, the CPM Schedule shall show the activity number, activity description, early start and early finish dates, late start and late finish dates, duration, total float value, and responsible Contractor, Subcontractor or other parties (including Owner). The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Guaranteed Commercial Operation Date, Guaranteed Substantial Completion Date and Guaranteed Final Completion Date. The CPM Schedule shall be submitted in hard copy and also in its native electronic format, provided on a computer diskette. Once the CPM Schedule and the required submittals have been reviewed and approved by Owner, this version of the CPM Schedule shall be the baseline CPM Schedule for the Work.
Sample 1

Related to CPM Schedule Submission

  • BACKGROUND STATEMENT The Borrower has requested that the Lenders make available to the Borrower a revolving credit facility in the aggregate principal amount of $100,000,000, subject to the availability provisions hereof. The Borrower will use the proceeds of these facilities as provided in Section 2.14. The Lenders are willing to make available to the Borrower the credit facilities described herein subject to and on the terms and conditions set forth in this Agreement.

  • Progress Reports 8. Within 30 days after the end of each calendar quarter following the date of this Agreement, the board of directors shall submit to the Reserve Bank written progress reports detailing the form and manner of all actions taken to secure compliance with the provisions of this Agreement and the results thereof, and a parent company only balance sheet, income statement, and, as applicable, report of changes in stockholders’ equity. Approval and Implementation of Plan

  • Disclosure Updates Promptly and in no event later than 5 Business Days after obtaining knowledge thereof, notify Agent if any written information, exhibit, or report furnished to the Lender Group contained, at the time it was furnished, any untrue statement of a material fact or omitted to state any material fact necessary to make the statements contained therein not misleading in light of the circumstances in which made. The foregoing to the contrary notwithstanding, any notification pursuant to the foregoing provision will not cure or remedy the effect of the prior untrue statement of a material fact or omission of any material fact nor shall any such notification have the effect of amending or modifying this Agreement or any of the Schedules hereto.

  • FINRA Submissions For a period of 60 days following the effective date of the Registration Statement, in the event any person or entity (regardless of any FINRA affiliation or association) is engaged to assist the Company in its search for a merger candidate or to provide any other merger and acquisition services, or has provided or will provide any investment banking, financial, advisory and/or consulting services to the Company, the Company agrees that it shall promptly provide to FINRA (via a FINRA submission), the Representative and its counsel a notification prior to entering into the agreement or transaction relating to a potential Business Combination: (i) the identity of the person or entity providing any such services; (ii) complete details of all such services and copies of all agreements governing such services prior to entering into the agreement or transaction; and (iii) justification as to why the value received by any person or entity for such services is not underwriting compensation for the Offering. The Company also agrees that proper disclosure of such arrangement or potential arrangement will be made in the tender offer materials or proxy statement, as applicable, which the Company may file in connection with the Business Combination for purposes of offering redemption of shares held by its stockholders or for soliciting stockholder approval, as applicable.

  • Regulatory Submissions From and after the Effective Date, NVS will[***] be responsible for (a) preparing, filing, and submitting, directly or through its Affiliates and permitted Sublicensees, all Regulatory Submissions for all Products in the Territory, and each material amendment or update thereto, in its name other than Jointly-Agreed Regulatory Submissions; and (b) interfacing, corresponding and meeting with Regulatory Authorities relating to Regulatory Submissions in the Territory for such Products; provided, that Regulatory Submissions and correspondence made to, and meetings held with, the FDA and EMA with respect to (i) [***] or (ii) [***] in each of (i) and (ii), will be prepared or conducted, as applicable, in collaboration with a representative from HMI’s regulatory team in accordance with this Article 7 (Regulatory Affairs); provided further that in all cases, such rights shall expressly exclude and not apply with Confidential Portions of this Exhibit marked as [***] have been omitted pursuant to a request for confidential treatment and have been filed separately with the Securities and Exchange Commission. Confidential Treatment Requested by Homology Medicines, Inc. respect to any data in Regulatory Submissions, correspondence, or meetings relating to any Other Components. Subject to Section 7.6 (Transfer of U.S. BLA for In-Vivo [***] Products), all Regulatory Approvals and Pricing Approvals for Products will be [***] owned by [***]. For all Products, NVS will timely inform HMI regarding the submission, receipt or denial of Regulatory Approval for such Product obtained or denied; provided, however, that NVS will inform HMI of such event prior to public disclosure of such event by NVS.

  • Development Reports Beginning six months after Effective Date and ending on the date of first commercial sale of a Licensed Product in the United States, LICENSEE shall report to Cornell progress covering LICENSEE's (and Affiliate's and Sublicensee's) activities and efforts in the development of rights granted to LICENSEE under this Agreement for the preceding six months. The report shall include, but not be limited to, activities and efforts to develop and test all Licensed Products and obtain governmental approvals necessary for marketing the same. Such semi-annual reports shall be due within sixty days (60) of the reporting period and shall use the form as provided herein as Appendix C.

  • SEC Filings and Press Releases To Agent and Lenders, promptly upon their becoming available, copies of: (i) all Financial Statements, reports, notices and proxy statements made publicly available by any Credit Party to its security holders; (ii) all regular and periodic reports and all registration statements and prospectuses, if any, filed by any Credit Party with any securities exchange or with the Securities and Exchange Commission or any governmental or private regulatory authority; and (iii) all press releases and other statements made available by any Credit Party to the public concerning material changes or developments in the business of any such Person.

  • Joint Proxy Statement None of the information supplied or to be supplied by or on behalf of Qwest for inclusion or incorporation by reference in the registration statement to be filed with the SEC by Qwest in connection with the issuance of shares of Qwest Common Stock in the Merger (the "Registration Statement") will, at the time the Registration Statement becomes effective under the Securities Act, contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein, in light of the circumstances under which they were made, not misleading. None of the information supplied or to be supplied by or on behalf of Qwest for inclusion or incorporation by reference in the joint proxy statement, in definitive form, relating to the meetings of Qwest and U S WEST stockholders to be held in connection with the Merger, or in the related proxy and notice of meeting, or soliciting material used in connection therewith (referred to herein collectively as the "Joint Proxy Statement") will, at the dates mailed to stockholders and at the times of the Qwest stockholders' meeting and the U S WEST stockholders' meeting, contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary in order to make the statements therein, in light of the circumstances under which they are made, not misleading. The Registration Statement and the Joint Proxy Statement (except for information relating solely to U S WEST) will comply as to form in all material respects with the provisions of the Securities Act and the Exchange Act and the rules and regulations promulgated thereunder.

  • Preparation of Proxy Statement Xxxxx shall prepare and file with the SEC the Proxy Statement at the earliest practicable date after the Offer has expired or terminated (unless 90% or more of outstanding Xxxxx Common Stock is acquired by Merger Sub pursuant to the Offer or Xxxxx Common Stock ceases to be registered under the Exchange Act in accordance with applicable law); and shall use all reasonable efforts to have the Proxy Statement cleared by the SEC. If at any time prior to the Effective Time any event shall occur that is required to be set forth in an amendment of or a supplement to the Proxy Statement, Xxxxx shall prepare and file with the SEC such amendment or supplement as soon thereafter as is reasonably practicable. Buyer, Merger Sub and Xxxxx shall cooperate with each other in the preparation of the Proxy Statement, and Xxxxx shall promptly notify Buyer of the receipt of any comments of the SEC with respect to the Proxy Statement and of any requests by the SEC for any amendment or supplement thereto or for additional information, and shall promptly provide to Buyer copies of all correspondence between Xxxxx or any representative of Xxxxx and the SEC with respect to the Proxy Statement. Xxxxx shall give Buyer and its counsel the opportunity to review the Proxy Statement and all responses to requests for additional information by and replies to comments of the SEC before their being filed with, or sent to, the SEC. If the Proxy Statement is required to be filed with the SEC, each of Xxxxx, Buyer and Merger Sub agrees to use all reasonable efforts, after consultation with the other parties hereto, to respond promptly to all such comments of and requests by the SEC and to cause the Proxy Statement to be mailed to the holders of Xxxxx Common Stock entitled to vote at the Shareholder Meeting at the earliest practicable time.

  • Registration Statement; Joint Proxy Statement (a) As promptly as practicable after the execution of this Agreement, Bergen and IVAX shall jointly prepare and IVAX and Bergen shall file with the SEC a document or documents that will constitute (i) the prospectus forming part of the registration statement on Form S-4 of BBI (together with all amendments thereto, the "Registration Statement"), in connection with the registration under the Securities Act of (A) the BBI Common Stock to be issued to IVAX's shareholders pursuant to the IVAX Merger and (B) the BBI Common Stock to be issued to Bergen's shareholders pursuant to the Bergen Merger, and (ii) the Joint Proxy Statement with respect to the Mergers relating to the special meeting of each of IVAX's shareholders (the "IVAX Shareholders' Meeting") and Bergen's shareholders (the "Bergen Shareholders' Meeting" and, together with the IVAX Shareholders' Meeting, the "Shareholders' Meetings") to be held to consider approval of this Agreement and the Mergers contemplated hereby (such document, together with any amendments thereto, the "Joint Proxy Statement"). Copies of the Joint Proxy Statement shall be provided to AMEX and the NYSE in accordance with the rules of such exchanges. Each of the parties hereto shall use all reasonable efforts to cause the Registration Statement to become effective as promptly as practicable, and, prior to the effective date of the Registration Statement, the parties hereto shall take all action required under any applicable Laws in connection with the issuance of shares of BBI Common Stock pursuant to the Mergers. Bergen or IVAX, as the case may be, shall furnish all information concerning Bergen or IVAX as the other party may reasonably request in connection with such actions and the preparation of the Registration Statement and Joint Proxy Statement. As promptly as practicable after the effective date of the Registration Statement, the Joint Proxy Statement shall be mailed to the shareholders of Bergen and IVAX. Each of the parties hereto shall cause the Joint Proxy Statement to comply as to form and substance in all material respects with the applicable requirements of (i) the Exchange Act, (ii) AMEX and the NYSE, (iii) the Securities Act and (iv) the FBCA, the NJBCA and the DGCL.

Time is Money Join Law Insider Premium to draft better contracts faster.