Coordination Drawings Sample Clauses

Coordination Drawings. 7.9.1 The A/E shall review the Coordination Drawings to determine whether the Coordination Participants achieved the goals established in the coordination meetings.
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
Coordination Drawings. In addition to other preconstruction services outlined elsewhere in the Contract Documents, Subcontractors and Suppliers shall prepare and participate in developing "coordination drawings" or similar input into an electronic model during the Design and Procurement Phase to identify routing and eliminate conflicts among the work of the various trades. The "coordination drawings" or similar input shall be provided to Architect, and necessary information shall be reflected and included in the Construction Documents that are submitted for permitting.
Sample 1Sample 2
Coordination Drawings. Contractor shall prepare coordination drawings as determined necessary by Metro to satisfactorily coordinate and interface its Work with the Work of all Other Metro Contractors, thereby avoiding conflicts that may arise.
Sample 1
Coordination Drawings. If applicable to SUBCONTRACTOR’S work, SUBCONTRACTOR shall prepare coordination drawings showing exact alignment, physical location and other required details for those portions of its work that must be coordinated with the work of CONTRACTOR, OWNER, or their other contractors, and shall participate in any related coordination efforts by CONTRACTOR.
Sample 1
Coordination Drawings. In addition to other preconstruction services outlined elsewhere in the Contract Documents, Trade Contractors are expected to prepare and participate in developing coordination drawings during the preconstruction phase to identify routing and eliminate conflicts among the work of the various trades. The coordination drawings shall be provided to Architect and Architect's Consultants and necessary information shall be reflected and included in the Design Documents, including the Contract Documents that are submitted for permitting.
Sample 1
Coordination Drawings. Layout plans and elevations drawn to scale and coordinating playground equipment with playground safety surface system and subsurface drainage system. Show playground equipment locations, use zones, fall heights, extent of protective surfacing and Critical Heights.
Sample 1
Coordination Drawings. In regards to coordinating space requirements, Subcontractor’s shop drawings are to include all pipe elevations relative to top of floor slab below as well as from bottom of deck above. A legend noting dimensions from centerline of piping to outside of piping and to outside of coupling, support, or insulation, whichever is lower, is required. Meetings for the purpose of coordinating space requirements among subcontractors will be conducted by Contractor as necessary. Where conflicts arise, Contractor will decide which subcontractor’s work will have priority. Late submittal of shop drawings may affect Subcontractor’s position in this regard. Minor relocations to eliminate spatial conflicts will be provided at no additional cost. If Subcontractor does not install its Work per coordinated drawings, Subcontractor will be responsible for reinstalling at the correct location and elevation at no additional cost to Contractor or Owner. If field conditions do not allow for Subcontractor to install per coordinated plans, Subcontractor is to notify Contractor immediately before proceeding with their Work.
Sample 1
AutoNDA by SimpleDocs
Coordination Drawings. If requested by Owner or Architect, Construction Manager shall submit drawings demonstrating coordination of the various portions of the Work, in such form and with such detail as required by Owner or Architect.
Sample 1
Coordination Drawings. 1. In addition to the coordination drawings Contractors, prepare additional drawings as required to assure coordination of the work to resolve conflicts.
Sample 1

Related to Coordination Drawings

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Selection of Architect/Construction Drawings Tenant shall retain the architect/space planner designated by Tenant and reasonably approved by Landlord (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.2. Tenant shall retain the engineering consultants selected by Tenant (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life safety, and sprinkler work in the Premises, which work is not part of the Base Building. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease shall specifically apply to the Construction Drawings.

  • Working Drawings Not later than 15 business days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlord’s receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the TI Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).

  • Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.

  • Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, Title 24 calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is sufficiently complete to allow all of Tenant’s Agents to bid on the work and to obtain all applicable permits (collectively, the ‘‘Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval, which shall not be unreasonably withheld, conditioned, or delayed. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings, Landlord shall not unreasonably withhold, condition, or delay its approval of the Final Working Drawings. Landlord shall approve or reasonably EXHIBIT A disapprove of the Final Working Drawings within ten (10) business days after Landlord’s receipt thereof. If Landlord reasonably withholds its approval, Landlord shall provide Tenant with the specific reasons therefor.

  • Non-Extension Drawings If the Liquidity Facility is scheduled to expire on a date (the “Stated Expiration Date”) prior to the date that is 15 days after the Final Maturity Date with respect to the ACS Group Loans, then, no earlier than the 60th day and no later than the 30th day prior to the applicable Stated Expiration Date then in effect, the Administrative Agent shall request that the Liquidity Facility Provider extend the Stated Expiration Date until the earlier of (i) the date which is 15 days after the Final Maturity Date with respect to the ACS Group Loans and (ii) the date that is immediately preceding the 364th day occurring after the Stated Expiration Date then in effect (unless the obligations of the Liquidity Facility Provider under the Liquidity Facility are earlier terminated in accordance with the Liquidity Facility). If on or before the date which is 10 days prior to the Stated Expiration Date, (A) the Liquidity Facility shall not have been replaced in accordance with Section 3.10(d) hereof or (B) the Liquidity Facility Provider fails irrevocably and unconditionally to advise the Administrative Agent that such Stated Expiration Date then in effect shall be so extended (whether or not the Administrative Agent has in fact requested an extension), the Administrative Agent shall immediately, in accordance with the terms of the Liquidity Facility (a “Non-Extended Facility”), request a drawing under such Liquidity Facility (such drawing, a “Non-Extension Drawing”) for the Available Amount thereunder. Amounts drawn pursuant to a Non-Extension Drawing shall be deposited into the Liquidity Facility Reserve Account.

  • Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

Time is Money Join Law Insider Premium to draft better contracts faster.