Third Party Beneficiaries This Agreement is intended for the benefit of the parties hereto and their respective permitted successors and assigns, and is not for the benefit of, nor may any provision hereof be enforced by, any other person.
No Third Party Beneficiaries This Agreement is intended for the benefit of the parties hereto and their respective permitted successors and assigns, and is not for the benefit of, nor may any provision hereof be enforced by, any other person.
Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
No Intended Third Party Beneficiaries This Agreement is entered into solely for the benefit of you and us. No third party will be deemed a beneficiary of this Agreement, and no third party will have the right to make any claim or assert any right under this Agreement. This provision does not affect the rights of third parties under any Third Party Terms.
Disclaimer of Third Party Beneficiaries This Agreement is made for the sole benefit of the Parties of this Agreement and their respective successors and assigns, and is not intended to and will not benefit any third party. No third party will have any rights under this Agreement, because of this Agreement or any right to enforce any provisions of this Agreement.
Assignment; Third Party Beneficiaries Neither this Agreement nor any of the rights, interests or obligations shall be assigned by any of the parties hereto (whether by operation of law or otherwise) without the prior written consent of the other parties. Subject to the preceding sentence, this Agreement will be binding upon, inure to the benefit of and be enforceable by the parties and their respective successors and assigns. Except as otherwise specifically provided in Section 6.8, this Agreement (including the documents and instruments referred to herein) is not intended to confer upon any person other than the parties hereto any rights or remedies hereunder.
No Third Party Beneficiary The terms and provisions of this Agreement are intended solely for the benefit of each party hereto and their respective successors or permitted assigns, and it is not the intention of the parties to confer third-party beneficiary rights upon any other Person.
Third Party Beneficiary The Holders shall be third party beneficiaries to the agreements made hereunder between the Company and the Guarantors, on the one hand, and the Initial Purchasers, on the other hand, and shall have the right to enforce such agreements directly to the extent they may deem such enforcement necessary or advisable to protect its rights or the rights of Holders hereunder.
Assignment; No Third Party Beneficiaries 5.2.1 This Agreement and the rights, duties and obligations of the Company hereunder may not be assigned or delegated by the Company in whole or in part.
Claims and Suits (a) The Receiver shall have the right, in its discretion, to (i) defend or settle any claim or suit against the Assuming Bank with respect to which the Receiver has indemnified the Assuming Bank in the same manner and to the same extent as provided in Article XII, and (ii) defend or settle any claim or suit against the Assuming Bank with respect to any Liability Assumed, which claim or suit may result in a loss to the Receiver arising out of or related to this Agreement, or which existed against the Failed Bank on or before Bank Closing. The exercise by the Receiver of any rights under this Section 9.3(a) shall not release the Assuming Bank with respect to any of its obligations under this Agreement.
