CONTRACTOR ACTION Sample Clauses

CONTRACTOR ACTION. After receipt of a notice of termination, and except as otherwise directed by the OWNER or Engineer, the CONTRACTOR shall:
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
CONTRACTOR ACTION. Responses to Requests for Information which do not involve a change in the Contract Price or Term, and which are consistent with the overall intent of the Original Agreement including the provisions of Change Order No. 1, shall be preformed by Contractor without additional claim or charge.
Sample 1Sample 2
CONTRACTOR ACTION. If the presence of Hazardous Materials on the Premises and any improvements from any source whatsoever results in contamination or deterioration of water or soil resulting in a level of contamination greater than the levels established as acceptable by any governmental agency having jurisdiction over such contamination, and if the Contractor is responsible therefore under applicable law, then Contractor shall, at its sole cost and expense, promptly take any and all action necessary to investigate and remediate such contamination if required by law or as a condition to the issuance or continuing effectiveness of any governmental approval which relates to the use of the Premises and any improvements or any part thereof. Contractor shall further be solely responsible for, and shall defend, indemnify and hold District and its agents harmless from and against, all claims, costs and liabilities, including attorneys' fees and costs, arising out of or in connection with any investigation and remediation required hereunder to return the Premises and any improvements to full compliance with all Hazardous Materials Laws.
Sample 1

Related to CONTRACTOR ACTION

  • Independent Contractor; Authority Notwithstanding the Services provided by the Administrator pursuant to this Agreement, the Administrator shall be deemed to be an independent contractor with respect to the Services. The management, policies and operations of the Parties (including the ultimate approval of the making or disposition of the Painting by the Issuer or Masterworks Cayman, and the terms and conditions thereof) shall be the responsibility of the Parties other than the Administrator.

  • Third Party Claim Procedures (a) The Indemnified Party seeking indemnification under Section 7.02 agrees to give reasonably prompt notice in writing to Indemnifying Party of the assertion of any claim or the commencement of any suit, action or proceeding by any third party (“Third Party Claim”) in respect of which indemnity may be sought under Section 7.02. Such notice shall set forth in reasonable detail such Third Party Claim and the basis for indemnification (taking into account the information then available to the Indemnified Party). The failure to so notify the Indemnifying Party shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent such failure shall have actually materially and adversely prejudiced the Indemnifying Party.

  • Third Party Contractors Tenant shall obtain and deliver to Landlord, Third Party Contractor’s certificates of insurance and applicable endorsements at least seven (7) business days prior to the commencement of work in or about the Premises by any vendor or any other third-party contractor (collectively, a “Third Party Contractor”). All such insurance shall (a) name Landlord as an additional insured under such party’s liability policies as required by Section 10.3.1 above and this Section 10.6, (b) provide a waiver of subrogation in favor of Landlord under such Third Party Contractor’s commercial general liability insurance, (c) be primary and any insurance carried by Landlord shall be excess and non-contributing, and (d) comply with Landlord’s minimum insurance requirements.

  • Third-Party Claim Indemnification Procedures (a) In the event that any written claim or demand for which an indemnifying party (an “Indemnifying Party”) may have liability to any Indemnified Party hereunder, other than those relating to Taxes (which are the exclusive subject of Article X), is asserted against or sought to be collected from any Indemnified Party by a third party (a “Third-Party Claim”), such Indemnified Party shall promptly, but in no event more than ten (10) days following such Indemnified Party’s receipt of a Third-Party Claim, notify the Indemnifying Party in writing of such Third-Party Claim, the amount or the estimated amount of damages sought thereunder to the extent then ascertainable (which estimate shall not be conclusive of the final amount of such Third-Party Claim), any other remedy sought thereunder, any relevant time constraints relating thereto and, to the extent practicable, any other material details pertaining thereto (a “Claim Notice”); provided, however, that the failure timely to give a Claim Notice shall affect the rights of an Indemnified Party hereunder only to the extent that such failure has a material prejudicial effect on the defenses or other rights available to the Indemnifying Party with respect to such Third-Party Claim. The Indemnifying Party shall have thirty (30) days (or such lesser number of days set forth in the Claim Notice as may be required by court proceeding in the event of a litigated matter) after receipt of the Claim Notice (the “Notice Period”) to notify the Indemnified Party that it desires to assume the defense of the Indemnified Party against such Third-Party Claim.

  • Officers and Trustees’ Good Faith Action, Expert Advice, No Bond or Surety The exercise by the Trustees of their powers and discretions hereunder shall be binding upon everyone interested. An officer or Trustee shall be liable to the Trust and to any Shareholder solely for such officer’s or Trustee’s own willful misfeasance, bad faith, gross negligence or reckless disregard of the duties involved in the conduct of the office of such officer or Trustee, and for nothing else, and shall not be liable for errors of judgment or mistakes of fact or law. The officers and Trustees may obtain the advice of counsel or other experts with respect to the meaning and operation of this Declaration of Trust and their duties as officers or Trustees. No such officer or Trustee shall be liable for any act or omission in accordance with such advice and no inference concerning liability shall arise from a failure to follow such advice. The officers and Trustees shall not be required to give any bond as such, nor any surety if a bond is required.

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • Third Party Claims If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a party to this Agreement or an Affiliate of a party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) calendar days after receipt of such notice of such Third-Party Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have the right to participate in, or by giving written notice to the Indemnified Party, to assume the defense of any Third-Party Claim at the Indemnifying Party’s expense and by the Indemnifying Party’s own counsel, and the Indemnified Party shall cooperate in good faith in such defense. In the event that the Indemnifying Party assumes the defense of any Third-Party Claim, subject to Section 8.03(b), it shall have the right to take such action as it deems necessary to avoid, dispute, defend, appeal or make counterclaims pertaining to any such Third-Party Claim in the name and on behalf of the Indemnified Party. The Indemnified Party shall have the right to participate in the defense of any Third-Party Claim with counsel selected by it subject to the Indemnifying Party’s right to control the defense thereof, provided that the fees and disbursements of such counsel shall be at the expense of the Indemnified Party.

  • Subcontractor Any vendor, subcontractor or other Person that is not responsible for the overall servicing (as “servicing” is commonly understood by participants in the mortgage-backed securities market) of Mortgage Loans but performs one or more discrete functions identified in Item 1122(d) of Regulation AB with respect to Mortgage Loans under the direction or authority of the Servicer or a Subservicer.

  • Contractor If COUNTY elects to renegotiate this Agreement due to reduced or terminated 20 funding, CONTRACTOR shall not be obligated to accept the renegotiated terms.

Time is Money Join Law Insider Premium to draft better contracts faster.