CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Employer is Name: Government of Madhya Pradesh (1.1) Water Resources Department Address: Mantralay, Bhopal Name of authorized Representative: Chief Engineer, Yamuna Basin, Water Resources Department, Gwalior (M.P.) The Engineer is (1.1) Name: Executive Engineer Address: W.R.Div. Morena (M.P.) Name of Authorized Representative: Executive Engineer X.X.Xxx.Xx 3 Morena (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : (1.1) *Address : (*to be filled in after the Adjudicator has been appointed) The name and identification number of the Contract is YB-7/B (BW) Restructuring and Modernization of Balance work of Khirawali Tank and its Canal System The Works consist of Earthwork, Xxxxxxxx Xxxxxx work, The Start Date shall be the date of issue of notice to proceed with the work. (1.1) The Intended Completion Date for the whole of the Works is 24 Months with the following milestones: [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order Milestone-1 25% 08 Months Milestone-2 60% 16 Months Milestone-3 100 % 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]
Appears in 2 contracts
CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh (1.1) Pradesh, Water Resources Department [1.1] Address: MantralayMantralaya, Bhopal Bhopal. Name of authorized Representative: Chief Engineer, Yamuna Chambal Betwa Basin, Water Resources Department, Gwalior (M.P.) Bhopal. The Engineer is (1.1) Name: Executive Engineer Address: W.R.Div. Morena (M.P.) Water Resources Division, Narsinghgarh Name of Authorized Representative: Executive Engineer X.X.Xxx.Xx 3 Morena (M.P.) Sub Divisional Officer, Narsinghgarh The Adjudicator appointed jointly by the Employer and Contractor is: *Name : (1.1) Mr……………………………………………. *Address Address: (*to be filled in after the Adjudicator has been appointed) …………………………………………………. The name and identification number of the Contract is YB-7/B Bid for RESTRUCTURING AND MODERNISATION OF HEAD WORKS AND CANALS OF AGAR-AGRI TANK (BWCB-34) Restructuring and Modernization of Balance work of Khirawali Tank and its Canal System [1.1] The Works consist of Earthworkre-sectioning and lining of distribution network, Xxxxxxxx Xxxxxx work, repair of canal structures and construction of new canal structures and other works. The Start Date shall be the date of issue of notice to proceed with the work. ([1.1) ] The Intended Completion Date for the whole of the Works is 24 Months months with the following milestones: . [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order Milestone-1 25% 08 Months Milestone-2 60% 16 Months Milestone-3 100 % 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]
Appears in 1 contract
Samples: www.mpwrd.gov.in
CONTRACT DATA. CONTRACT DATA Contract Data Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals Manual [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India and SPMU Gujarat is a recipient of the credit under [1.1] The World Bank means “International Bank for Reconstruction and Development (IBRD)” or International Development Association (XXX), “as appropriate], The above insertions should correspond to the information provided in the Invitation of Bids. The Employer is NameName : Government of Madhya Pradesh Director Address : Gujarat Ecological Education & Research (1.1XXXX) Water Resources Department Address: MantralayFoundation, Bhopal Gandhinagar Name of authorized Representative: Chief EngineerNodal Officer, Yamuna BasinGujarat Ecological Education & Research (XXXX) Foundation, Water Resources Department, Gwalior (M.P.) Gandhinagar The Engineer is (1.1) NameName : Executive Engineer AddressAddress : W.R.Div. Morena (M.P.) Gujarat Ecological & Education Research Foundation, Gandhinagar Name of Authorized RepresentativeRepresentative : Executive Engineer X.X.Xxx.Xx 3 Morena (M.P.) Xxxx The Adjudicator appointed jointly by the Employer and Contractor is: *Name : Xx. X X Xxxxx (1.1) *Address : (*to be filled in after the Adjudicator has been appointed) Rt. Chief Engineer, GWSSB, Shardhadeep Society, B/h central school, Kalavad Road, Rajkot The name and identification number of the Contract is YB-7is.(NCB/B (BWICZMP/XXXX/02) Restructuring and Modernization Construction & Establishment of Balance work of Khirawali Tank and its Canal System The Works consist of EarthworkResearch Station & Field Station for XXXX Foundation at Bhavanagar, Xxxxxxxx Xxxxxx workXxxxx, Jamnagar. The Start Date shall be the date of issue of notice to proceed with the work. (1.1) The Intended Completion Date completion date for the whole of the Works works is 24 6 (Six) Calendar Months with the following milestonesmilestones for following Packages: [17, 28] Package 1: Milestone dates Financial progress to be achieved Physical Work Period from the date of the issue of notice to proceed with the work. Construction & Establishment of Research Station & Field Station for XXXX Foundation at Bhavnagar 1 Complete the Earthwork in excavation in foundation with anti-termite treatment and refilling and Providing & Laying Cement Concrete M20 including complete work order Milestone-1 25% 08 of centering & form work and steel work. One Month from the date of Award of Contract 3 Complete RCC work like lintels, beams, root slabs, etc. Three and half Months Milestone-2 60% 16 from the Date of award of Contract 4 Providing & fixing the flooring and Door & windows Four and half Months Milestone-3 100 % 24 from the Date of award of Contract 5 Providing & fixing of plumbing material and complete the painting work. Five Months from the Date of award of Contract Package 2: Milestone Physical Work Period from the date of the issue of notice to proceed with the work. Construction & Establishment of Research Station & Field Station for XXXX Foundation at Bhavnagar 1 Complete the Earthwork in excavation in foundation with anti-termite treatment and refilling and Providing & Laying Cement Concrete M20 including complete work of centering & form work and steel work. One Month from the date of Award of Contract 3 Complete RCC work like lintels, beams, root slabs, etc. Three and half Months from the Date of award of Contract 4 Providing & fixing the flooring and Door & windows Four and half Months from the Date of award of Contract 5 Providing & fixing of plumbing material and complete the painting work. Five Months from the Date of award of Contract Package 3: Milestone Physical Work Period from the date of the issue of notice to proceed with the work. Construction & Establishment of Research Station & Field Station for XXXX Foundation at Bhavnagar 1 Complete the Earthwork in excavation in foundation with anti-termite treatment and refilling and Providing & Laying Cement Concrete M20 including complete work of centering & form work and steel work. One Month from the date of Award of Contract 3 Complete RCC work like lintels, beams, root slabs, etc. Three and half Months from the Date of award of Contract 4 Providing & fixing the flooring and Door & windows Four and half Months from the Date of award of Contract 5 Providing & fixing of plumbing material and complete the painting work. Five Months from the Date of award of Contract The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer engineer shall reasonably prescribe) within 15 14 days of delivery of the Letter of Acceptance. [27]
Appears in 1 contract
Samples: www.geerfoundation.gujarat.gov.in
CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh (1.1) Pradesh, Water Resources Department [1.1] Address: MantralayMantralaya, Bhopal Bhopal. Name of authorized Representative: Chief Engineer, Yamuna Chambal Betwa Basin, Water Resources Department, Gwalior Department Bhopal (M.P.) ). The Engineer is (1.1) Name: Executive Engineer Engineer, Address: W.R.Div. Morena Water Resources Division SEHORE (M.P.) Name of Authorized Representative: Executive Engineer X.X.Xxx.Xx 3 Morena Sub Divisional Officer Water Resources Sub Dn, Ichhawar Distt Sehore (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : (1.1) Mr……………………………………………. *Address Address: (*to be filled in after the Adjudicator has been appointed) …………………………………………………. The name and identification number of the Contract is YB-7/B (BW) Restructuring and Modernization of Balance work of Khirawali Tank and its Canal System RESTRUCTURING AND MODERNIZATION OF HEAD WORK AND CANALS OF MOONDLA TANK PACKAGE NO. CB/ 32A [1.1] The Works consist of Earthworkre-sectioning and lining of distribution network, Xxxxxxxx Xxxxxx work, repair of canal structures and construction of new canal structures and other works. The Start Date shall be the date of issue of notice to proceed with the work. ([1.1) ] The Intended Completion Date for the whole of the Works is 24 Months months with the following milestones: . [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 25% 08 Months Milestone-2 60% 16 Months Milestone-3 100 % 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]
Appears in 1 contract
Samples: www.mpwrd.gov.in
CONTRACT DATA. CONTRACT DATA Contract Data Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N58](N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [1414 The Borrower is Government of India/ Government of Madhya Pradesh [1.1] [name of Xxxxxxxx and statement of relationship with the Employer, if different from the Borrower]. The World Bank means International Bank for Reconstruction [1.1] and Development (IBRD) and loan refers to an “IBRD Loan” 4750 IN The above insertions should correspond to the information provided in the Invitation of Bids. The Employer is Name: Government of Madhya Pradesh Water Resources Department (1.1) Water Resources Department Address: Mantralay, Bhopal Name of authorized Representative: Chief Engineer, Yamuna BasinXxxxxx-Xxx Xxxxx, Water Resources Department, Gwalior (M.P.) Sagar. The Engineer is (1.1) Name: Executive Engineer Address: W.R.Div. Morena (M.P.) Water Resources Xx Xx 0, Xxxxx Name of Authorized Representative: Executive Engineer X.X.Xxx.Xx 3 Morena (M.P.) Sub Divisional Officer, WR Sub Dn,Shagarh The Adjudicator appointed jointly by the Employer and Contractor is: *Name : (1.1) *Address : (*to be filled in after the Adjudicator has been appointed) The name and identification number of the Contract is YB-7/B RESTRUCTURING & MODERNISATION OF DISTRIBUTION SYSTEM OF BILA TANK (BWDK/13A) Restructuring and Modernization of Balance work of Khirawali Tank and its Canal System The Works consist of Earthwork, Xxxxxxxx Xxxxxx work, Construction and repair of old canal structures & resectioning and lining of Canal The Start Date shall be the date of issue of notice to proceed with the work. (1.1) The Intended Completion Date for the whole of the Works is 24 Months 26 months with the following milestones: [17, 28] Milestone dates Financial progress to be achieved Period from the date of issue of work order Milestone-1 25% 08 09 Months Milestone-2 60% 16 17 Months Milestone-3 100 % 24 26 Months The following documents also form part of the Contract: [2.3] NIL Nil The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]] [This program should be in adequate detail and generally conform to the program submitted alongwith bid in response to ITB Clause 4.3 (k). Deviations if any from that should be clearly explained and should be satisfactory to the Engineer] The Site Possession Dates shall be: Within 15 days after the issue of the Work order The Site is Located at Sagar Division. The Defects Liability Period is 365 days from the date of certification of completion of works. (where sectional completion certificate is issued this will apply from those dates for those sections). Insurance requirements are as under: [13] Minimum Cover for Insurance Maximum deductible for Insurance
Appears in 1 contract
Samples: www.mpwrd.gov.in
CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh (1.1) Pradesh, Water Resources Department [1.1] Address: MantralayMantralaya, Bhopal Bhopal. Name of authorized Representative: Chief Engineer, Yamuna Chambal Betwa Basin, Water Resources Department, Gwalior Department Bhopal (M.P.) The Engineer is ([1.1) ] Name: Executive Engineer Engineer, Address: W.R.Div. Morena Water Resources Division, Narsingarh (M.P.) Name of Authorized Representative: Executive Engineer X.X.Xxx.Xx 3 Morena Sub Divisional Officer Water Resources Sub Division. Narsinghgarh (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : (1.1) Mr……………………………………………. *Address Address: (*to be filled in after the Adjudicator has been appointed) …………………………………………………. The name and identification number of the Contract is YB-7/B (BW) Restructuring and Modernization of Balance work of Khirawali Tank and its Canal System RESTRUCTURING AND MODERNIZATION OF HEAD WORKS AND CANALS OF XXXXXXX XXX AND TINONIA TANK [1.1] The Works consist of- The Works consist of EarthworkRe-sectioning of dam & spill channel, Xxxxxxxx Xxxxxx workrepair of sluice, repairing of pitching of main bund, re-sectioning of canal in selected reaches and lining in U/S and D/S of existing structures (1.1) 62 The Start Date shall be the date of issue of notice to proceed with the work. ([1.1) ] The Intended Completion Date for the whole of the Works is 24 Months 16 months with the following milestones: [17, 28] . Milestone dates Cumulative Financial progress to be achieved Period from the date of issue of work order notice to proceed with the work Milestone-1 2545% 08 05 Months Milestone-2 6055% 16 13 Months Milestone-3 100 % 24 16 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27].
Appears in 1 contract
Samples: www.mpwrd.gov.in
CONTRACT DATA. CONTRACT DATA Items marked "N/A" do not apply in this Contract. The following documents are also part of the Contract: Clause Reference · The Schedule of Operating and Maintenance Manuals [58] (N/A) · The Schedule of Other Contractors [8] · The Schedule of Key Personnel [9] · The Methodology and Program of Construction & Environmental Management Plan [27] · The Schedule of Key and Critical equipment to be deployed [27] on the work as per agreed program of construction · Site Investigation reports [14] The Borrower is Government of India/ Govt. of M.P. [1.1] The World Bank means International Bank for Reconstruction and Development (IBRD) [1.1] and loan refers to an I.B.R.D. Loan The Employer is Name: Government of Madhya Pradesh (1.1) Pradesh, Water Resources Department [1.1] Address: MantralayMantralaya, Bhopal Bhopal. Name of authorized Representative: Chief Engineer, Yamuna Chambal Betwa Basin, Water Resources Department, Gwalior Department Bhopal (M.P.) The Engineer is ([1.1) ] Name: Executive Engineer Engineer, Address: W.R.Div. Morena Water Resource Division, Vidisha, (M.P.) Name of Authorized Representative: Executive Engineer X.X.Xxx.Xx 3 Morena Sub Divisional Officer Water Resources Sub Division, Basoda (M.P.) The Adjudicator appointed jointly by the Employer and Contractor is: *Name : (Mr……………………………………………. [1.1) ] *Address Address: (*to be filled in after the Adjudicator has been appointed) …………………………………………………. The name and identification number of the Contract is YB-7/B (BW) Restructuring and Modernization modernization of Balance work Distribution System of Khirawali Xxxxxx Tank and its Canal System [1.1] The Works consist of Earthworkre-sectioning and lining of distribution network, Xxxxxxxx Xxxxxx work, repair of canal structures and construction of new canal structures and other works. The Start Date shall be the date of issue of notice to proceed with the work. ([1.1) ] The Intended Completion Date for the whole of the Works is 24 Months months with the following milestones: . [17, 28] Milestone dates Financial progress to be achieved Achieved Period from the date of issue of work order Milestone-1 2520% 08 Months Milestone-2 6050% 16 Months Milestone-3 100 % 24 Months The following documents also form part of the Contract: [2.3] NIL The Contractor shall submit a revised Program including Environmental Management Plan for the Works (in such form and detail as the Engineer shall reasonably prescribe) within 15 days of delivery of the Letter of Acceptance. [27]
Appears in 1 contract
Samples: www.mpwrd.gov.in
