Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Exhibit D - Debarment Certification By signing and submitting this Contract, the Contractor is agreeing to abide by the debarment requirements as set out below. • The certification in this clause is a material representation of fact relied upon by County. • The Contractor shall provide immediate written notice to County if at any time the Contractor learns that its certification was erroneous or has become erroneous by reason of changed circumstances. • Contractor certifies that none of its principals, affiliates, agents, representatives or contractors are excluded, disqualified or ineligible for the award of contracts by any Federal agency and Contractor further certifies to the best of its knowledge and belief, that it and its principals: • Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded by any Federal Department or Agency; • Have not been convicted within the preceding three-years of any of the offenses listed in 2 CFR 180.800(a) or had a civil judgment rendered against it for one of those offenses within that time period; • Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State, or Local) with commission of any of the offenses listed in 2 CFR 180.800(a); • Have not had one or more public transactions (Federal, State, or Local) terminated within the preceding three-years for cause or default. • The Contractor agrees by signing this Contract that it will not knowingly enter into any subcontract or covered transaction with a person who is proposed for debarment, debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction. • Any subcontractor will provide a debarment certification that includes the debarment clause as noted in preceding bullets above, without modification.
Management Certifications In addition to the responsibilities set forth in this CIA for all Covered Persons, certain employees for the U.S. Healthcare Supply DMEPOS Companies (Certifying Employees) are expected to monitor and oversee activities within their areas of authority and shall annually certify that the applicable department for the U.S. Healthcare Supply DMEPOS Companies is in compliance with applicable Federal health care program requirements and the obligations of this CIA. These Certifying Employees shall include, at a minimum, the following individuals at U.S. Healthcare Supply, LLC, Spectrum Diabetic Services, LLC, Heritage Diabetic Supply, Inc, and Dependable Diabetic Supply, LLC: any Covered Person with the title and job responsibilities of Chief Executive Officer, President, Compliance Officer, Chief Operating Officer, Chief Financial Officer, director, or manager. For each Reporting Period, each Certifying Employee shall sign a certification that states: “I have been trained on and understand the compliance requirements and responsibilities as they relate to [insert name of department], an area under my supervision. My job responsibilities include ensuring compliance with regard to the [insert name of department] with all applicable Federal health care program requirements, obligations of the Corporate Integrity Agreement, and [insert name of applicable entity] policies, and I have taken steps to promote such compliance. To the best of my knowledge, the [insert name of department] of [insert name of applicable entity] is in compliance with all applicable Federal health care program requirements and the obligations of the Corporate Integrity Agreement. I understand that this certification is being provided to and relied upon by the United States.” If any Certifying Employee is unable to provide such a certification, the Certifying Employee shall provide a written explanation of the reasons why he or she is unable to provide the certification outlined above. Within 90 days after the Effective Date, the U.S. Healthcare Supply DMEPOS Companies shall develop and implement a written process for Certifying Employees to follow for the purpose of completing the certification required by this section (e.g., reports that must be reviewed, assessments that must be completed, sub-certifications that must be obtained, etc. prior to the Certifying Employee making the required certification).
Drawings and Specifications at the Project Site The Contractor shall keep at the Site at least one copy of the Contract Documents and Change Orders, all in good order and available to the Design Professional and to his representatives.
Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Project Engineer If the Project has been designed by the Project Engineer, the Project Engineer is to act as the Owner's representative, assumes all duties and responsibilities, and has the rights and authority assigned to Project Engineer in the Contract Documents in connection with completion of the Work all in accordance with the Contract Documents.
Certification of Contractor The Contractor shall certify, over his own signature, that the Work provided for by the Contract Documents has been completed under the terms and conditions thereof, and that the entire balance of the contract is due and payable.
Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
