CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.
Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and
Construction of Hotel (i) To Seller’s knowledge, the Hotel has been constructed in a good and workmanlike manner without encroachments except as noted on the Survey and in accordance in all material respects with the Construction Plans. To Seller’s knowledge, the Hotel has received all building permits and certificates of occupancy necessary for the operation thereof, and is in compliance with applicable zoning, platting, subdivision, health, safety and similar laws, rules, regulations, ordinances and codes.
Construction of Language Whenever appropriate in the Agreement, words used in the singular may be read in the plural, words used in the plural may be read in the singular, and words importing the masculine gender may be read as referring equally to the feminine or the neuter. Any reference to a section shall be a reference to a section of this Agreement, unless the context clearly indicates otherwise. Capitalized terms not specifically defined herein shall have the meanings assigned to them under the Plan.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Conflict; Construction of Documents In the event of any conflict between the provisions of this Agreement and any of the other Loan Documents, the provisions of this Agreement shall control. The parties hereto acknowledge that each is represented by separate counsel in connection with the negotiation and drafting of the Loan Documents and that the Loan Documents shall not be subject to the principle of construing their meaning against the party that drafted them.
Conflict; Construction of Documents; Reliance In the event of any conflict between the provisions of this Agreement and any of the other Loan Documents, the provisions of this Agreement shall control. The parties hereto acknowledge that they were represented by competent counsel in connection with the negotiation, drafting and execution of the Loan Documents and that such Loan Documents shall not be subject to the principle of construing their meaning against the party which drafted same. Borrower acknowledges that, with respect to the Loan, Borrower shall rely solely on its own judgment and advisors in entering into the Loan without relying in any manner on any statements, representations or recommendations of Lender or any parent, subsidiary or Affiliate of Lender. Lender shall not be subject to any limitation whatsoever in the exercise of any rights or remedies available to it under any of the Loan Documents or any other agreements or instruments which govern the Loan by virtue of the ownership by it or any parent, subsidiary or Affiliate of Lender of any equity interest any of them may acquire in Borrower, and Borrower hereby irrevocably waives the right to raise any defense or take any action on the basis of the foregoing with respect to Lender’s exercise of any such rights or remedies. Borrower acknowledges that Lender engages in the business of real estate financings and other real estate transactions and investments which may be viewed as adverse to or competitive with the business of Borrower or its Affiliates.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.
