Construction Estimates Sample Clauses

Construction Estimates. The Construction Manager shall prepare an Estimate of Construction Cost as soon as major Project requirements have been identified and update it periodically. For the Schematic Design Phase, the Construction Manager shall prepare a quantity take-off cost estimate based on building systems, assemblies, components, etc., and update periodically. During the Design Development Phase, the Construction Manager shall prepare a final cost estimate in preparation for a Guaranteed Maximum Price and update periodically. All Estimates of Construction Cost shall make allowance for bidding and price escalation. During the Construction Documents Phase, the Construction Manager shall continually monitor the cost estimates and develop a cost estimate to help assure that the cost of the Work remains within the applicable portion of the Project Budget, Fixed Limit of Construction Cost and Guaranteed Maximum Price.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Construction Estimates. The Construction Manager, if requested by the Owner’s Project Representative, shall provide a preliminary evaluation of the Owner’s Project program and budget. At the request of the Owner’s Project Representative, the Construction Manager shall prepare and deliver to the Owner’s Project Representative and the Architect, Construction Estimates as follows:
Sample 1
Construction Estimates a) It is expressly understood that statements of probable construction cost and detailed cost estimates prepared by Envision represent best judgment only. It is recognized that neither CEPT nor Envision have any control over cost of material, labor or equipment, over the Contractor's methods of determining bid prices or over competitive bidding or market conditions.
Sample 1
Construction Estimates. Estimates of contract time, construction costs and quantities prepared by the Engineer or its employees represent their best professional judgment as design professionals and are supplied for the general guidance of the District. The Engineer does not guarantee the accuracy of such estimates as the Engineer has no control over the cost of labor and material, competitive bidding, or market or other conditions.
Sample 1
Construction Estimates. Estimates of construction cost, material quantities and construction time estimates provided by ENGINEER under this Agreement represent its opinion and are subject to change and are contingent upon factors over which ENGINEER has no control. ENGINEER makes no warranty, express or implied, as to the accuracy of such estimates.
Sample 1
Construction Estimates. The Design/Build Entity shall prepare an Estimate of Design & Construction as soon as major Project requirements have been identified and update it periodically. For the Schematic Design Phase, the Design/Build Entity shall prepare a quantity take-off cost estimate based on building systems, assemblies, components, etc., and update periodically. During the Design Development Phase, the Design/Build Entity shall prepare a final cost estimate in preparation for a Guaranteed Maximum Price and update periodically. All Estimates of Design & Construction shall make allowance for bidding and price escalation. During the Construction Documents Phase, the Design/Build Entity shall continually monitor the cost estimates and develop a cost estimate to help assure that the cost of the Work remains within the applicable portion of the Project Budget, Fixed Limit of Design & Construction Cost and Guaranteed Maximum Price.
Sample 1

Related to Construction Estimates

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Repair Estimate If the Premises or the Building are damaged by fire or other casualty (a “Casualty”), Landlord shall use good faith efforts to deliver to Tenant within sixty (60) days after such Casualty a good faith estimate (the “Damage Notice”) of the time needed to repair the damage caused by such Casualty.

  • USE OF ESTIMATES The Sponsor is authorized to make all Net Asset Value determinations (including, without limitation, for purposes of determining redemption payments and calculating Sponsor’s Fees) on the basis of estimated numbers. The Sponsor shall not (unless the Sponsor otherwise determines) attempt to make any retroactive adjustments in order to reflect the differences between such estimated and the final numbers, but rather shall reflect such differences in the Accounting Period in which final numbers become available. The Sponsor also shall not (unless the Sponsor otherwise determines) revise Sponsor’s Fee calculations to reflect differences between estimated and final numbers (including differences which have resulted in economic benefit to a Sponsor Party). If, after payment of redemption proceeds, the Sponsor determines that adjustment to the Net Asset Value of the redeemed Units is necessary, the redeeming Investor (if the Net Asset Value is adjusted upwards) or the remaining Investors (if the Net Asset Value is adjusted downwards) will bear the risk of such adjustment. The redeeming Investor will neither receive further distributions from, nor will it be required to reimburse, this FuturesAccess Fund in such circumstances.

  • Estimates User shall pay to Tenant, in advance on a monthly basis, an amount equal to the estimated Rent for each year of the Use Period or part thereof divided by the number of months therein. Attached as Exhibit B is an budget for the Project prepared by Tenant and approved by User, which reflects a good faith estimate of Rent. Based on Exhibit B, the parties have agreed that User will pay to Tenant the monthly sum allocated to User on Exhibit B, in advance, as Tenant’s initial estimate of Rent. From time to time, Tenant may estimate and re-estimate the amount of Rent to be due and deliver a copy of the estimate or re-estimate to User. Thereafter, the monthly installments of Rent shall be appropriately adjusted in accordance with the estimations so that, by the end of the calendar year in question, User shall have paid all of Rent estimated by Tenant for such calendar year. Any amounts paid based on such an estimate shall be subject to adjustment as herein provided when the actual amount of Rent is available for each calendar year or fraction thereof (in the instance of any partial calendar year).

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Construction Budget The total amount indicated by the District for the Project plus all other costs, including design, construction, administration, financing, and all other costs.

  • Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.

  • Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:

  • Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.

Time is Money Join Law Insider Premium to draft better contracts faster.